etrn-20220331

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549

FORM 10-Q


(Mark One)

☒			QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

FOR THE QUARTERLY PERIOD ENDED MARCH 31, 2022


or

☐	TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

	FOR THE TRANSITION PERIOD FROM TO

	COMMISSION FILE NUMBER	001-38629

EQUITRANS MIDSTREAM CORPORATION

(Exact name of registrant as specified in its charter)


Pennsylvania						83-0516635
(State or other jurisdiction of incorporation or organization)						(IRS Employer Identification No.)

2200 Energy Drive, Canonsburg, Pennsylvania 15317

(Address of principal executive offices) (Zip code)

(724) 271-7600


(Registrant's telephone number, including area code)

Securities registered pursuant to Section 12(b) of the Act:

Title of each class

Trading Symbol

Name of each exchange on which registered

Common Stock, no par value

ETRN

New York Stock Exchange

Indicate by check mark whether the registrant: (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes ☒ No ☐

Indicate by check mark whether the registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T (§ 232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit such files). Yes ☒ No ☐

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company, or an emerging growth company. See the definitions of "large accelerated filer," "accelerated filer," "smaller reporting company" and "emerging growth company" in Rule 12b-2 of the Exchange Act.

Large Accelerated Filer

☒

Accelerated Filer

☐

Emerging Growth Company

☐

Non-Accelerated Filer

☐

Smaller Reporting Company

☐

If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. ☐

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes ☐ No ☒

The number of shares of common stock outstanding (in thousands), as of April 30, 2022: 432,763

EQUITRANS MIDSTREAM CORPORATION

Index


			Page No.

Glossary of Commonly Used Terms, Abbreviations and Measurements			3

Part I.	Financial Information:

Item 1.		Financial Statements (Unaudited):

		Statements of Consolidated Comprehensive Income for the Three Months Ended March 31, 2022 and 2021	5

		Statements of Consolidated Cash Flows for the Three Months Ended March 31, 2022 and 2021	6

		Consolidated Balance Sheets as of March 31, 2022 and December 31, 2021	7

		Statements of Consolidated Equity and Mezzanine Equity for the Three Months Ended March 31, 2022 and 2021	8

		Notes to Consolidated Financial Statements	9

Item 2.		Management's Discussion and Analysis of Financial Condition and Results of Operations	17

Item 3.		Quantitative and Qualitative Disclosures About Market Risk	32

Item 4.		Controls and Procedures	35

Part II.	Other Information:

Item 1.		Legal Proceedings	36

Item 1A.		Risk Factors	40

Item 2.		Unregistered Sales of Equity Securities and Use of Proceeds	40

Item 6.		Exhibits	41

Signature			42

Table of Contents

EQUITRANS MIDSTREAM CORPORATION

Glossary of Commonly Used Terms, Abbreviations and Measurements

2021 Water Services Agreement – that certain mixed-use water services agreement entered into on October 22, 2021 by the Company and EQT (as defined below), as subsequently amended, which became effective on March 1, 2022 and replaced the Water Services Letter Agreement (as defined below) and certain other existing Pennsylvania water services agreements.

Allowance for Funds Used During Construction (AFUDC) – carrying costs for the construction of certain long-lived regulated assets are capitalized and amortized over the related assets' estimated useful lives. The capitalized amount for construction of regulated assets includes interest cost and a designated cost of equity for financing the construction of these regulated assets.

Amended EQM Credit Facility – that certain unsecured revolving credit facility of EQM Midstream Partners, LP, as previously amended and restated, including by an amendment entered on March 30, 2020 (such facility, as so amended in March 2020, the First Amended EQM Credit Facility) and a subsequent amendment entered into on April 16, 2021.

Amended 2019 EQM Term Loan Agreement - that certain term loan agreement entered into in August 2019 and amended on March 30, 2020 by EQM, which term loan agreement was terminated on January 8, 2021.

Annual Revenue Commitments (ARC or ARCs) - contractual term in a water services agreement that obligates the customer to pay for a fixed amount of water services annually.

Appalachian Basin – the area of the United States composed of those portions of West Virginia, Pennsylvania, Ohio, Maryland, Kentucky and Virginia that lie in the Appalachian Mountains.

associated gas – natural gas that is produced as a byproduct of principally oil production activities.

British thermal unit – a measure of the amount of energy required to raise the temperature of one pound of water one-degree Fahrenheit.

delivery point – the point where gas is delivered into a downstream gathering system or transmission pipeline.

EQM – EQM Midstream Partners, LP and its subsidiaries.

EQT – EQT Corporation (NYSE: EQT) and its subsidiaries.

EQT Global GGA – that certain Gas Gathering and Compression Agreement entered into on February 26, 2020 (the EQT Global GGA Effective Date) by the Company with EQT and certain affiliates of EQT for the provision of certain gas gathering services to EQT in the Marcellus and Utica Shales of Pennsylvania and West Virginia, as subsequently amended.

firm contracts – contracts for gathering, transmission, storage and water services that reserve an agreed upon amount of pipeline or storage capacity regardless of the capacity used by the customer during each month, and generally obligate the customer to pay a fixed, monthly charge.

firm reservation fee revenues – contractually obligated revenues that include fixed monthly charges under firm contracts and fixed volumetric charges under MVC (as defined below) and ARC (as defined above) contracts.

gas – natural gas.

liquefied natural gas (LNG) – natural gas that has been cooled to minus 161 degrees Celsius for transportation, typically by ship. The cooling process reduces the volume of natural gas by 600 times.

Minimum volume commitments (MVC or MVCs) – contracts for gathering or water services that obligate the customer to pay for a fixed amount of volumes daily, monthly, annually or over the life of the contract.

Mountain Valley Pipeline (MVP) – an estimated 300-mile, 42-inch diameter natural gas interstate pipeline with a targeted capacity of 2.0 Bcf per day that is designed to span from the Company's existing transmission and storage system in Wetzel County, West Virginia to Pittsylvania County, Virginia, providing access to the growing Southeast demand markets.

Mountain Valley Pipeline, LLC (MVP Joint Venture) – a joint venture among the Company and, as applicable, affiliates of each of NextEra Energy, Inc., Consolidated Edison, Inc. (Con Edison), AltaGas Ltd. and RGC Resources, Inc. that is constructing the MVP and the MVP Southgate (as defined below) projects.

Table of Contents

MVP Southgate – a proposed 75-mile interstate pipeline that is contemplated to extend from the MVP at Pittsylvania County, Virginia to new delivery points in Rockingham and Alamance Counties, North Carolina. The project is subject to ongoing discussions between the MVP Joint Venture and the project shipper, Dominion Energy North Carolina, as discussed in Part I, "Outlook" in "Item 2. Management's Discussion and Analysis of Financial Condition and Results of Operations" of this Quarterly Report on Form 10-Q.

natural gas liquids (NGLs) – those hydrocarbons in natural gas that are separated from the gas as liquids through the process of absorption, condensation, adsorption or other methods in gas processing plants. Natural gas liquids include ethane, propane, butane and iso-butane.

Preferred Interest – the preferred interest that the Company has in EQT Energy Supply, LLC (EES), a subsidiary of EQT.

throughput – the volume of natural gas transported or passing through a pipeline, plant, terminal or other facility during a particular period.

Water Services Letter Agreement – that certain letter agreement entered into on February 26, 2020 by the Company and EQT, pursuant to which EQT agreed to utilize the Company for the provision of water services in Pennsylvania under existing water services agreements and new water services agreements if negotiated between the parties, which letter agreement was replaced by the 2021 Water Services Agreement on March 1, 2022.

wellhead – the equipment at the surface of a well used to control the well's pressure and the point at which the hydrocarbons and water exit the ground.

Unless the context otherwise requires, a reference to a “Note” herein refers to the accompanying Notes to Consolidated Financial Statements contained in Part I, "Item 1. Financial Statements."


Abbreviations			Measurements
ASC – Accounting Standards Codification			Btu = one British thermal unit
ASU – Accounting Standards Update			BBtu = billion British thermal units
EPA – U.S. Environmental Protection Agency			Bcf = billion cubic feet
FASB – Financial Accounting Standards Board			Mcf = thousand cubic feet
FERC – U.S. Federal Energy Regulatory Commission			MMcf = million cubic feet
GAAP – United States Generally Accepted Accounting Principles			MMgal = million gallons
IRS – United States Internal Revenue Service
NGA – Natural Gas Act of 1938
NYMEX – New York Mercantile Exchange
NYSE – New York Stock Exchange
SEC – U.S. Securities and Exchange Commission

Table of Contents

PART I. FINANCIAL INFORMATION

Item 1. Financial Statements

EQUITRANS MIDSTREAM CORPORATION

Statements of Consolidated Comprehensive Income (Unaudited)


	Three Months Ended March 31,
		2022		2021
		(Thousands, except per share amounts)
Operating revenues		$	342,146	$	379,996
Operating expenses:
Operating and maintenance		32,834		34,099
Selling, general and administrative		28,126		35,494

Depreciation		67,043		68,618
Amortization of intangible assets		16,205		16,205


Total operating expenses		144,208		154,416
Operating income		197,938		225,580
Equity income (a)		4		3
Other income, net		6,348		7,599
Loss on extinguishment of debt		—		(41,025)
Net interest expense		(93,121)		(95,144)
Income before income taxes		111,169		97,013
Income tax expense		6,261		20,416
Net income		104,908		76,597
Net income attributable to noncontrolling interests		3,775		3,914
Net income attributable to Equitrans Midstream		101,133		72,683






Preferred dividends		14,628		14,628
Net income attributable to Equitrans Midstream common shareholders		$	86,505	$	58,055

Earnings per share of common stock attributable to Equitrans Midstream common shareholders - basic		$	0.20	$	0.13


Earnings per share of common stock attributable to Equitrans Midstream common shareholders - diluted		$	0.20	$	0.13

Weighted average common shares outstanding - basic		433,318		432,983
Weighted average common shares outstanding - diluted		433,913		433,158

Statement of comprehensive income:
Net income		$	104,908	$	76,597
Other comprehensive income, net of tax:
Pension and other post-retirement benefits liability adjustment, net of tax expense of $12 and $12		34		34
Other comprehensive income		34		34
Comprehensive income		104,942		76,631
Less: Comprehensive income attributable to noncontrolling interests		3,775		3,914
Less: Comprehensive income attributable to preferred dividends		14,628		14,628
Comprehensive income attributable to Equitrans Midstream common shareholders		$	86,539	$	58,089

Dividends declared per common share		$	0.15	$	0.15

(a)Represents equity income from Mountain Valley Pipeline, LLC (the MVP Joint Venture). See Note 5.

The accompanying notes are an integral part of these consolidated financial statements.

Table of Contents

EQUITRANS MIDSTREAM CORPORATION

Statements of Consolidated Cash Flows (Unaudited)


	Three Months Ended March 31,
	2022		2021
	(Thousands)
Cash flows from operating activities:
Net income	$	104,908	$	76,597
Adjustments to reconcile net income to net cash provided by operating activities:
Depreciation	67,043		68,618
Amortization of intangible assets	16,205		16,205
Deferred income taxes	4,603		20,406

Equity income	(4)		(3)
Other income	(6,501)		(7,254)
Loss on extinguishment of debt	—		41,025
Non-cash long-term compensation expense	2,990		4,445
Changes in other assets and liabilities:
Accounts receivable	34,759		17,725

Accounts payable	(7,679)		1,337
Accrued interest	(74,812)		(46,934)
Deferred revenue	86,652		72,019
Other assets and other liabilities	(42,218)		(34,634)
Net cash provided by operating activities	185,946		229,552
Cash flows from investing activities:
Capital expenditures	(71,285)		(61,265)
Capital contributions to the MVP Joint Venture	(72,537)		(10,723)

Principal payments received on the Preferred Interest	1,351		1,277

Net cash used in investing activities	(142,471)		(70,711)
Cash flows from financing activities:
Proceeds from revolving credit facility borrowings	55,000		77,500
Payments on revolving credit facility borrowings	(112,000)		(70,000)
Proceeds from the issuance of long-term debt	—		1,900,000

Debt discounts, debt issuance costs and credit facility arrangement fees	—		(24,204)

Payment for retirement of long-term debt	—		(1,936,250)







Dividends paid to holders of Equitrans Midstream Preferred Shares	(14,628)		(14,628)

Dividends paid to common shareholders	(64,901)		(64,871)







Distributions to noncontrolling interests	—		(2,500)
Net cash used in financing activities	(136,529)		(134,953)

Net change in cash and cash equivalents	(93,054)		23,888
Cash and cash equivalents at beginning of period	134,661		208,023
Cash and cash equivalents at end of period	$	41,607	$	231,911

Cash paid during the period for:
Interest, net of amount capitalized	$	165,631	$	140,199
Cash paid for taxes	$	815	$	—

The accompanying notes are an integral part of these consolidated financial statements.

Table of Contents

EQUITRANS MIDSTREAM CORPORATION

Consolidated Balance Sheets (Unaudited)


	March 31, 2022		December 31, 2021
	(Thousands)
ASSETS
Current assets:
Cash and cash equivalents	$	41,607	$	134,661

Accounts receivable (net of allowance for credit losses of $2,683 and $2,696 as of March 31, 2022 and December 31, 2021, respectively)	231,985		252,301



Other current assets	52,306		59,867
Total current assets	325,898		446,829

Property, plant and equipment	9,061,829		9,004,602
Less: accumulated depreciation	(1,278,247)		(1,217,099)
Net property, plant and equipment	7,783,582		7,787,503

Investment in unconsolidated entity	1,278,992		1,239,039
Goodwill	486,698		486,698
Net intangible assets	635,567		651,771




Other assets	307,965		308,924
Total assets	$	10,818,702	$	10,920,764

LIABILITIES, MEZZANINE EQUITY AND SHAREHOLDERS' EQUITY
Current liabilities:

Accounts payable	$	47,649	$	59,627

Capital contributions payable to the MVP Joint Venture	39,159		72,188
Accrued interest	77,097		151,909
Accrued liabilities	43,814		83,852
Total current liabilities	207,719		367,576

Long-term liabilities:
Revolving credit facility borrowings	448,000		505,000
Long-term debt	6,437,703		6,434,945


Contract liability	907,994		821,342


Regulatory and other long-term liabilities	97,156		99,333
Total liabilities	8,098,572		8,228,196


Mezzanine equity:
Equitrans Midstream Preferred Shares, 30,018 shares issued and outstanding as of March 31, 2022 and December 31, 2021	681,842		681,842

Shareholders' equity:

Common stock, no par value, 432,677 and 432,522 shares issued and outstanding as of March 31, 2022 and December 31, 2021, respectively	3,960,588		3,957,756
Retained deficit	(2,407,250)		(2,428,171)
Accumulated other comprehensive loss	(2,020)		(2,054)
Total common shareholders' equity	1,551,318		1,527,531
Noncontrolling interests	486,970		483,195
Total shareholders' equity	2,038,288		2,010,726
Total liabilities, mezzanine equity and shareholders' equity	$	10,818,702	$	10,920,764

The accompanying notes are an integral part of these consolidated financial statements.

Table of Contents

EQUITRANS MIDSTREAM CORPORATION

Statements of Consolidated Shareholders' Equity and Mezzanine Equity (Unaudited)


												Mezzanine
												Equity
						Accumulated						Equitrans
	Common Stock					Other						Midstream
	Shares	No		Retained		Comprehensive		Noncontrolling		Total		Preferred
	Outstanding	Par Value		Deficit		Loss		Interests		Equity		Shares
	(Thousands, except per share amounts)
Balance at January 1, 2021	432,470	$	3,941,295	$	(728,959)	$	(2,229)	$	471,165	$	3,681,272	$	681,842
Other comprehensive income (net of tax):
Net income	—	—		58,055		—		3,914		61,969		14,628
Pension and other post-retirement benefits liability adjustment, net of tax expense of $12	—	—		—		34		—		34		—
Dividends on common shares ($0.15 per share)	—	—		(64,984)		—		—		(64,984)		—
Share-based compensation plans, net	28	4,662		—		—		—		4,662		—
Distributions paid to noncontrolling interests	—	—		—		—		(2,500)		(2,500)		—
Dividends paid to holders of Equitrans Midstream Preferred Shares ($0.4873 per share)	—	—		—		—		—		—		(14,628)




Balance at March 31, 2021	432,498	$	3,945,957	$	(735,888)	$	(2,195)	$	472,579	$	3,680,453	$	681,842



												Mezzanine
												Equity
						Accumulated						Equitrans
	Common Stock					Other						Midstream
	Shares	No		Retained		Comprehensive		Noncontrolling		Total		Preferred
	Outstanding	Par Value		Deficit		Loss		Interests		Equity		Shares
	(Thousands, except per share amounts)
Balance at January 1, 2022	432,522	$	3,957,756	$	(2,428,171)	$	(2,054)	$	483,195	$	2,010,726	$	681,842
Other comprehensive income (net of tax):
Net income	—	—		86,505		—		3,775		90,280		14,628
Pension and other post-retirement benefits liability adjustment, net of tax expense of $12	—	—		—		34		—		34		—
Dividends on common shares ($0.15 per share)	—	—		(65,584)		—		—		(65,584)		—
Share-based compensation plans, net	155	2,832		—		—		—		2,832		—

Dividends paid to holders of Equitrans Midstream Preferred Shares ($0.4873 per share)	—	—		—		—		—		—		(14,628)




Balance at March 31, 2022	432,677	$	3,960,588	$	(2,407,250)	$	(2,020)	$	486,970	$	2,038,288	$	681,842

The accompanying notes are an integral part of these consolidated financial statements.

Table of Contents

EQUITRANS MIDSTREAM CORPORATION

Notes to Consolidated Financial Statements (Unaudited)

1. Financial Statements

Nature of Business. The Company provides midstream services to its customers in Pennsylvania, West Virginia and Ohio through its three primary assets: the gathering system, which includes predominantly dry gas gathering systems of high-pressure gathering lines; the transmission system, which includes FERC-regulated interstate pipelines and storage systems; and the water network, which primarily consists of water pipelines and other facilities that support well completion activities and produced water handling activities.

Basis of Presentation. References in these financial statements to Equitrans Midstream or the Company refer collectively to Equitrans Midstream Corporation and its consolidated subsidiaries for all periods presented, unless otherwise indicated.

The accompanying unaudited consolidated financial statements have been prepared in accordance with generally accepted accounting principles in the United States (GAAP) for interim financial information and with the requirements of Form 10-Q and Article 10 of Regulation S-X. Accordingly, they do not include all of the information and footnotes required by GAAP for complete financial statements. In the opinion of management, these unaudited consolidated financial statements include all adjustments (consisting of only normal, recurring adjustments, unless otherwise disclosed in this Quarterly Report on Form 10-Q) necessary for a fair presentation of the financial position of the Company as of March 31, 2022, the results of its operations, cash flows and equity for the three months ended March 31, 2022 and 2021. The consolidated balance sheet at December 31, 2021 has been derived from the audited financial statements at that date but does not include all of the information and notes required by GAAP for complete financial statements. This Quarterly Report on Form 10-Q should be read in conjunction with the Company's Annual Report on Form 10-K for the year ended December 31, 2021, which includes all disclosures required by GAAP.

Due to, among other things, the seasonal nature of the Company's utility customer contracts, as well as producers’ well completion activities and varying needs for fresh and produced water (which are primarily driven by horizontal lateral lengths and the number of completion stages per well), the interim statements for the three months ended March 31, 2022 are not necessarily indicative of the results that may be expected for the year ending December 31, 2022.

For further information, refer to the Company's annual consolidated financial statements and related notes in the Company's Annual Report on Form 10-K for the year ended December 31, 2021, as well as Part I, "Item 2. Management's Discussion and Analysis of Financial Condition and Results of Operations" contained herein.

Recently Issued Accounting Standards.

In March 2020, the FASB issued ASU 2020-04, Reference Rate Reform (Topic 848), which provides practical expedients for contract modifications and certain hedging relationships associated with the transition from reference rates that are expected to be discontinued. This guidance is applicable for the Amended EQM Credit Facility and the 2021 Eureka Credit Facility (as defined in Note 6), as well as for each dividend following March 31, 2024 for the Equitrans Midstream Preferred Shares, which each use the London Inter-Bank Offered Rate (LIBOR) as a reference rate. The ASU was effective immediately but is only available through December 31, 2022. The Company is currently evaluating the potential impact of this standard on its financial statements and related disclosures.

In August 2020, the FASB issued ASU 2020-06, Accounting for Convertible Instruments and Contracts in an Entity’s Own Equity, which simplifies the accounting for convertible debt and convertible preferred stock by removing the requirements to separately present certain conversion features in equity. In addition, the amendments in the ASU 2020-06 also simplify the guidance in ASC Subtopic 815-40, Derivatives and Hedging: Contracts in Entity’s Own Equity, by removing certain criteria that must be satisfied in order to classify a contract as equity. Finally, the amendments revise the guidance on calculating earnings per share, requiring use of the if-converted method for all convertible instruments and rescinding an entity’s ability to rebut the presumption of share settlement for instruments that may be settled in cash or other assets. The amendments were effective for fiscal years beginning after December 15, 2021. The Company adopted this standard on January 1, 2022 with no significant effect on the Company's financial statements or related disclosures.

Table of Contents

2. Financial Information by Business Segment

The Company reports its operations in three segments that reflect its three lines of business of Gathering, Transmission and Water, which reflects the manner in which management evaluates the business for making operating decisions and assessing performance.


	Three Months Ended March 31,
		2022		2021
		(Thousands)
Revenues from customers:
Gathering		$	219,790	$	250,076
Transmission		110,795		111,419
Water		11,561		18,501
Total operating revenues		$	342,146	$	379,996
Operating income (loss):
Gathering		$	115,621	$	139,854
Transmission		84,562		81,488
Water		(1,856)		4,477
Headquarters (a)		(389)		(239)
Total operating income		$	197,938	$	225,580

Reconciliation of operating income to net income:
Equity income (b)		$	4	$	3
Other income, net (c)		6,348		7,599
Loss on extinguishment of debt		—		(41,025)
Net interest expense		(93,121)		(95,144)
Income tax expense		6,261		20,416
Net income		$	104,908	$	76,597

(a)Includes certain unallocated corporate expenses.

(b)Equity income is included in the Transmission segment.

(c)Includes unrealized gains on derivative instruments recorded in the Gathering segment.


	March 31, 2022		December 31, 2021
	(Thousands)
Segment assets:
Gathering	$	7,610,869	$	7,638,877
Transmission (a)	2,798,661		2,769,097
Water	148,875		151,151
Total operating segments	10,558,405		10,559,125
Headquarters, including cash	260,297		361,639
Total assets	$	10,818,702	$	10,920,764

(a)The equity investment in the MVP Joint Venture is included in the Transmission segment.

Table of Contents


	Three Months Ended March 31,
		2022		2021
		(Thousands)
Depreciation:
Gathering		$	48,255	$	46,547
Transmission		13,894		13,800
Water		4,517		8,175
Headquarters		377		96
Total		$	67,043	$	68,618
Capital expenditures:
Gathering (a)		$	53,147	$	48,113
Transmission (b)		4,226		3,505
Water		9,565		4,807
Headquarters		12		1,157
Total (c)		$	66,950	$	57,582

(a)Includes capital expenditures related to the noncontrolling interest in Eureka Midstream Holdings, LLC (Eureka Midstream) of approximately $3.0 million and $1.7 million for the three months ended March 31, 2022 and 2021, respectively.

(b)Transmission capital expenditures do not include aggregate capital contributions made to the MVP Joint Venture for the MVP and MVP Southgate projects of approximately $72.5 million and $10.7 million for the three months ended March 31, 2022 and 2021, respectively.

(c)The Company accrues capital expenditures when the work has been completed but the associated bills have not yet been paid. Accrued capital expenditures are excluded from the statements of consolidated cash flows until they are paid. The net impact of non-cash capital expenditures, including the effect of accrued capital expenditures, transfers to/from inventory as assets are completed/assigned to a project and capitalized share-based compensation costs, was $4.3 million and $3.7 million for the three months ended March 31, 2022 and 2021, respectively.

3. Revenue from Contracts with Customers

For the three months ended March 31, 2022 and 2021, all revenues recognized on the Company's statements of consolidated comprehensive income are from contracts with customers. As of March 31, 2022 and December 31, 2021, all receivables recorded on the Company's consolidated balance sheets represented performance obligations that have been satisfied and for which an unconditional right to consideration exists.

Summary of disaggregated revenues. The tables below provide disaggregated revenue information by business segment.


	Three Months Ended March 31, 2022
	Gathering		Transmission		Water		Total
	(Thousands)
Firm reservation fee revenues (a)	$	132,597	$	102,870	$	5,752	$	241,219
Volumetric-based fee revenues	87,193		7,925		5,809		100,927

Total operating revenues	$	219,790	$	110,795	$	11,561	$	342,146

	Three Months Ended March 31, 2021
	Gathering		Transmission		Water		Total
	(Thousands)
Firm reservation fee revenues (a)	$	148,192	$	101,389	$	1,844	$	251,425
Volumetric-based fee revenues (b)	101,884		10,030		16,657		128,571

Total operating revenues	$	250,076	$	111,419	$	18,501	$	379,996

(a) For the three months ended March 31, 2022, firm reservation fee revenues associated with Gathering included approximately $2.7 million of MVC unbilled revenues. For the three months ended March 31, 2021, firm reservation fee revenues associated with Gathering and Water included approximately $3.2 million and $0.5 million of MVC unbilled revenue, respectively.

(b) For the three months ended March 31, 2021, volumetric-based fee revenues associated with Gathering included approximately $6.2 million of unbilled revenues.

Contract assets. The Company's contract assets related to the Company's future MVC deficiency payments are generally expected to be collected within the next twelve months and are primarily included in other current assets in the Company's consolidated balance sheets until such time as the MVC deficiency payments are invoiced to the customer.

The following table presents changes in the Company's unbilled revenue balance during the three months ended March 31, 2022 and 2021:


	Unbilled Revenue
	2022		2021
	(Thousands)
Balance as of beginning of period	$	16,772	$	18,618
Revenue recognized in excess of amounts invoiced (a)	4,692		10,188
Minimum volume commitments invoiced (b)	(14,884)		(16,931)
Amortization (c)	(110)		—
Balance as of end of period	$	6,470	$	11,875

(a)Primarily includes revenues associated with MVCs that are generally included in firm reservation fee revenues within the Gathering and Water segments. During the three months ended March 31, 2021, also includes other contractual commitments of approximately $6.2 million.

(b)Unbilled revenues are transferred to accounts receivable once the Company has an unconditional right to consideration from the customer.

(c)Amortization of capitalized contract costs paid to customers over the expected life of the agreement.

Contract liabilities. The Company's contract liabilities consisted of deferred revenue primarily associated with the EQT Global GGA. Contract liabilities are classified as current or non-current according to when such amounts are expected to be recognized. As of March 31, 2022, total contract liabilities were $909.1 million, of which $1.1 million was classified as current and recorded in accrued liabilities and $908.0 million was classified as non-current and recorded in contract liability on the Company's consolidated balance sheet. As of December 31, 2021, total contract liabilities were $822.4 million, of which $1.1 million was classified as current and recorded in accrued liabilities and $821.3 million was classified as non-current and recorded in contract liability on the Company's consolidated balance sheet.

The following table presents changes in the Company's contract liability balances during the three months ended March 31, 2022 and 2021:


	Contract Liability
	2022		2021
	(Thousands)
Balance as of beginning of period	$	822,416	$	398,750
Amounts recorded during the period (a)	86,920		72,019

Amounts transferred during the period (b)	(268)		$	—
Balance as of end of period	$	909,068	$	470,769

(a)Includes deferred billed revenue during the three months ended March 31, 2022 and 2021 primarily associated with the EQT Global GGA.

(b)Deferred revenues are recognized as revenue upon satisfaction of the Company's performance obligation to the customer.

Summary of remaining performance obligations. The following table summarizes the estimated transaction price allocated to the Company's remaining performance obligations under all contracts with firm reservation fees, MVCs and/or ARCs as of March 31, 2022 that the Company will invoice or transfer from contract liabilities and recognize in future periods.


		2022(a)		2023		2024		2025		2026		Thereafter		Total
	(Thousands)
Gathering firm reservation fees		$	65,980	$	105,804	$	157,621	$	150,060	$	141,227	$	1,277,907	$	1,898,599
Gathering revenues supported by MVCs		334,378		457,843		429,233		448,262		459,424		3,477,205		5,606,345
Transmission firm reservation fees		260,613		359,260		376,572		363,629		358,800		3,228,443		4,947,317
Water revenues supported by ARCs		28,125		37,500		37,500		37,500		37,500		193,750		371,875
Total (b)		$	689,096	$	960,407	$	1,000,926	$	999,451	$	996,951	$	8,177,305	$	12,824,136

(a) April 1, 2022 through December 31, 2022.

(b) Includes assumptions regarding timing for placing certain projects in-service. Such assumptions may not be realized and delays in the in-service dates for projects have substantially altered, and additional delays may further substantially alter, the remaining performance obligations for certain contracts with firm reservation fees, MVCs and/or ARCs. The MVP Joint Venture is accounted for as an equity investment and those amounts are not included in the table above.

Based on total projected contractual revenues, including projected contractual revenues from future capacity expected from expansion projects that are not yet fully constructed for which the Company has executed firm contracts, the Company's firm gathering contracts and firm transmission and storage contracts had weighted average remaining terms of approximately 14 years and 13 years, respectively, as of March 31, 2022.

4. Related Party Transactions

As of March 31, 2022, EQT was a related party of the Company due to its ownership of 22,796,026 shares of Equitrans Midstream common stock, which represented an approximately 5.3% ownership interest in the Company, excluding the impact of the Equitrans Midstream Preferred Shares. In the ordinary course of business, the Company engaged, and continues to engage, as applicable, in transactions with EQT and its affiliates, including, but not limited to, entering into new or amending existing gathering agreements, transportation service and precedent agreements, storage agreements and water services agreements. As of May 3, 2022, EQT is no longer a related party of the Company.

The following table summarizes the Company's related party transactions.


	Three Months Ended March 31,
		2022		2021
		(Thousands)
Operating revenues		$	198,386	$	224,957
Equity income		4		3
Interest income from the Preferred Interest		1,395		1,469
Capital contributions to the MVP Joint Venture		(72,537)		(10,723)
Principal payments received on the Preferred Interest		1,351		1,277

The following table summarizes the Company's related party receivables and payables.


	March 31, 2022		December 31, 2021
	(Thousands)
Accounts receivable	$	168,114	$	190,410
Contract asset	—		2,246
Investment in unconsolidated entity	1,278,992		1,239,039
Preferred Interest	98,487		99,838
Capital contributions payable to the MVP Joint Venture	39,159		72,188
Contract liability	905,578		818,658

Table of Contents

5. Investment in Unconsolidated Entity

The MVP Joint Venture is constructing the Mountain Valley Pipeline (MVP), an estimated 300-mile natural gas interstate pipeline that is designed to span from northern West Virginia to southern Virginia. The Company will operate the MVP and owned a 47.0% interest in the MVP project as of March 31, 2022. On November 4, 2019, Consolidated Edison, Inc. (Con Edison) exercised an option to cap its investment in the construction of the MVP project at approximately $530 million (excluding AFUDC). The Company and NextEra Energy, Inc. are obligated to, and RGC Resources, Inc., another member of the MVP Joint Venture owning an interest in the MVP project, has opted to, fund the shortfall in Con Edison's capital contributions, on a pro rata basis. Such funding by the Company and funding by other members has and will correspondingly increase the Company's and such other funding members' respective interests in the MVP project and decrease Con Edison's interest in the MVP project. As a result, based on the Company's targeted cost for the project of approximately $6.6 billion (excluding AFUDC), the Company's equity ownership in the MVP project will progressively increase from approximately 47.0% to approximately 48.1%. The MVP Joint Venture is a variable interest entity because it has insufficient equity to finance its activities during the construction stage of the project. The Company is not the primary beneficiary of the MVP Joint Venture because the Company does not have the power to direct the activities that most significantly affect the MVP Joint Venture's economic performance. Certain business decisions, such as decisions to make distributions of cash, require a greater than 66 2/3% ownership interest approval, and no one member owns more than a 66 2/3% interest.

In April 2018, the MVP Joint Venture announced the MVP Southgate project, which is a proposed 75-mile interstate pipeline that is contemplated to extend from the MVP at Pittsylvania County, Virginia to new delivery points in Rockingham and Alamance Counties, North Carolina. The Company is expected to operate the MVP Southgate pipeline and owned a 47.2% interest in the MVP Southgate project as of March 31, 2022. The MVP Joint Venture continues to evaluate the MVP Southgate project, including engaging in discussions with the project shipper, Dominion Energy North Carolina, regarding options with respect to the project, including potentially refining the project’s design and timing in lieu of pursuing the project as originally contemplated. Dominion Energy North Carolina’s obligations under the precedent agreement in support of the original project are subject to certain conditions, including that the MVP Joint Venture complete construction of the project facilities by June 1, 2022, which deadline is subject to extension by virtue of previously declared events of force majeure. The Company is unable to predict the results of the discussions between the MVP Joint Venture and Dominion Energy North Carolina, including any potential modifications to the project, or ultimate undertaking or completion of the project.

In the fourth quarter of 2021, the Company incurred an other-than-temporary decline in value in its equity investment in the MVP Joint Venture, primarily due to unfavorable decisions by the U.S. Fourth Circuit Court of Appeals that vacated and remanded key authorizations, that resulted in a pre-tax impairment charge of $1.9 billion. As a result of the impairment, the carrying value of the Company's equity investment in the MVP Joint Venture was reduced to $1.2 billion as of December 31, 2021. There is risk that the Company's equity investment in the MVP Joint Venture may be further impaired in the future due to ongoing (and potentially future) legal and regulatory matters, as well as potential macroeconomic factors, including market fluctuations, changes in interest rates, cost increases and other unanticipated events.

In March 2022, the MVP Joint Venture issued a capital call notice for the funding of the MVP project to MVP Holdco, LLC (MVP Holdco), a wholly owned subsidiary of the Company, for $39.1 million, of which $18.2 million was paid in May 2022, and $20.9 million is expected to be paid in June 2022. The capital contributions payable and the corresponding increase to the investment balance are reflected on the consolidated balance sheet as of March 31, 2022.

Pursuant to the MVP Joint Venture's limited liability company agreement, MVP Holdco is obligated to provide performance assurances, which may take the form of a guarantee from EQM (provided that EQM's debt is rated as investment grade in accordance with the requirements of the MVP Joint Venture's limited liability company agreement), a letter of credit or cash collateral, in favor of the MVP Joint Venture to provide assurance as to the funding of MVP Holdco's proportionate share of the construction budget for the MVP project.

In addition, pursuant to the MVP Joint Venture's limited liability company agreement, MVP Holdco is obligated to provide performance assurances in respect of MVP Southgate, which performance assurances may take the form of a guarantee from EQM (provided that EQM's debt is rated as investment grade in accordance with the requirements of the MVP Joint Venture's limited liability company agreement), a letter of credit or cash collateral.

Based on EQM’s credit rating levels, EQM has delivered replacement credit support to the MVP Joint Venture in the form of letters of credit, which, in the case of the MVP project is in the amount of approximately $219.7 million and, in the case of the MVP Southgate, is in the amount of approximately $14.2 million, in each case, as of March 31, 2022. The amount of each of the letters of credit is subject to adjustment based upon the applicable project's construction budget. Upon the FERC’s initial release to begin construction of the MVP Southgate project, the Company's then-current letter of credit to support MVP Southgate will be terminated, and the Company will be obligated to deliver a new letter of credit (or provide another allowable

Table of Contents

form of performance assurance) in an amount equal to 33% of MVP Holdco’s proportionate share of the remaining capital obligations for the MVP Southgate project under the applicable construction budget.

The following tables summarize the unaudited condensed consolidated financial statements of the MVP Joint Venture in relation to the MVP project.

Condensed Consolidated Balance Sheets


	March 31, 2022		December 31, 2021
	(Thousands)
Current assets	$	82,570	$	148,820
Non-current assets	6,515,268		6,432,288
Total assets	$	6,597,838	$	6,581,108

Current liabilities	$	146,148	$	160,331

Equity	6,451,690		6,420,777
Total liabilities and equity	$	6,597,838	$	6,581,108

Condensed Statements of Consolidated Operations


	Three Months Ended March 31,
		2022		2021
		(Thousands)
Operating expenses		$	(1)	$	—
Other income		10		6


Net income		$	9	$	6

6. Debt

Amended EQM Revolving Credit Facility. As of March 31, 2022, the Company had aggregate commitments available of $2.25 billion under the Amended EQM Credit Facility, which is set to mature in October 2023. As of March 31, 2022, EQM had approximately $180 million of borrowings and $234.9 million of letters of credit outstanding under the Amended EQM Credit Facility. As of December 31, 2021, EQM had approximately $225 million of borrowings and $234.9 million of letters of credit outstanding under the Amended EQM Credit Facility. During the three months ended March 31, 2022, the maximum outstanding borrowings at any time was approximately $280 million and the average daily balance was approximately $260 million. EQM incurred interest at a weighted average annual interest rate of approximately 2.8% for the three months ended March 31, 2022. During the three months ended March 31, 2021, the maximum outstanding borrowings at any time was approximately $525 million and the average daily balance was approximately $489 million. EQM incurred interest at a weighted average annual interest rate of approximately 2.5% for the three months ended March 31, 2021. For the three months ended March 31, 2022, commitment fees of $1.8 million were paid to maintain credit availability under the Amended EQM Credit Facility. For the three months ended March 31, 2021, commitment fees of $2.3 million were paid to maintain credit availability under the First Amended EQM Credit Facility. As of March 31, 2022, no term loans were outstanding under the Amended EQM Credit Facility.

See Note 10 for discussion of the Third Amendment (as defined in Note 10) to the Amended EQM Credit Facility.

Amended 2019 EQM Term Loan Agreement. On January 8, 2021, EQM (i) applied a portion of the proceeds from the issuance of the 2021 Senior Notes (as defined below) to prepay all principal, interest, fees and other obligations outstanding under the Amended 2019 EQM Term Loan Agreement and (ii) terminated the Amended 2019 EQM Term Loan Agreement and the loan documents associated therewith. EQM repaid outstanding term loans (the EQM Term Loans) with a principal amount of $1.4 billion in connection with the termination of the Amended 2019 EQM Term Loan Agreement. Prior to its termination in January 2021, the Amended 2019 EQM Term Loan Agreement would have matured in August 2022. During the period from January 1, 2021 through January 7, 2021, the weighted average annual interest rate was approximately 2.4%.

Eureka Credit Facilities. On May 13, 2021, Eureka Midstream, LLC (Eureka), a wholly owned subsidiary of Eureka Midstream, repaid all outstanding principal borrowings plus accrued and unpaid interest under and terminated its credit facility

Table of Contents

with ABN AMRO Capital USA LLC, as administrative agent, the lenders party thereto from time to time and any other persons party thereto from time to time (the Former Eureka Credit Facility). In conjunction with the termination of, and to fund the repayment of all outstanding amounts under the Former Eureka Credit Facility, on May 13, 2021, Eureka entered into a $400 million senior secured revolving credit facility with Sumitomo Mitsui Banking Corporation, as administrative agent, the lenders party thereto from time to time and any other persons party thereto from time to time (the 2021 Eureka Credit Facility).

As of March 31, 2022, and December 31, 2021, Eureka had approximately $268 million and $280 million, respectively, of borrowings outstanding under the 2021 Eureka Credit Facility. For the three months ended March 31, 2022, the maximum amount of outstanding borrowings under the 2021 Eureka Credit Facility at any time was approximately $280 million and the average daily balance was approximately $277 million and Eureka incurred interest at a weighted average annual interest rate of approximately 2.9%. For the three months ended March 31, 2022, commitment fees of $0.1 million were paid to maintain credit availability under the 2021 Eureka Credit Facility. For the three months ended March 31, 2021, the maximum amount of outstanding borrowings under the Former Eureka Credit Facility at any time was approximately $310 million, the average daily balance was approximately $305 million and Eureka incurred interest at a weighted average annual interest rate of approximately 2.4%. For the three months ended March 31, 2021, commitment fees of $0.1 million were paid to maintain credit availability under the Former Eureka Credit Facility.

2021 Senior Notes. During the first quarter of 2021, EQM issued, in a private offering, $800 million aggregate principal amount of new 4.50% senior notes due 2029 (the 2029 Notes) and $1,100 million aggregate principal amount of new 4.75% senior notes due 2031 (the 2031 Notes and, together with the 2029 Notes, the 2021 Senior Notes) and received net proceeds from the offering of approximately $1,876.5 million (excluding costs related to the Tender Offers discussed below), inclusive of a discount of $19 million and debt issuance costs of $4.5 million. EQM used the net proceeds from the offering of the 2021 Senior Notes and cash on hand to repay all outstanding borrowings under the Amended 2019 EQM Term Loan Agreement, to purchase an aggregate principal amount of $500 million of its outstanding 4.75% notes due 2023 (2023 Notes) pursuant to tender offers for certain of EQM's outstanding indebtedness (such tender offers, the Tender Offers), and for general partnership purposes.

Tender Offers. On January 15, 2021 (the early tender deadline), the maximum principal amount for the Tender Offers was fully subscribed by the 2023 Notes tendered as of the early tender deadline and on January 20, 2021, EQM purchased an aggregate principal amount of $500 million of 2023 Notes at an aggregate cost of approximately $537 million (inclusive of the applicable early tender premium for the 2023 Notes described in that certain Offer to Purchase of EQM dated January 4, 2021, as amended, plus accrued interest).

The Company incurred a loss on the extinguishment of debt of $41.0 million during the three months ended March 31, 2021 related to the payment of the Tender Offer premium and write off of unamortized discounts and financing costs related to the prepayment of the EQM Term Loans under, and termination of, the Amended 2019 EQM Term Loan Agreement and purchase of 2023 Notes in the Tender Offers. This amount is included in the loss on extinguishment of debt line on the statements of consolidated comprehensive income.

As of March 31, 2022, EQM and Eureka were in compliance with all debt provisions and covenants.

7. Fair Value Measurements

Assets Measured at Fair Value on a Recurring Basis. The Company records derivative instruments at fair value on a gross basis in its consolidated balance sheets. The EQT Global GGA provides for potential cash bonus payments payable by EQT to the Company during the period beginning on the first day of the calendar quarter in which the MVP full in-service date occurs through the calendar quarter ending December 31, 2024 (the Henry Hub cash bonus payment provision). The potential cash bonus payments are conditioned upon the quarterly average of certain Henry Hub natural gas prices exceeding certain price thresholds. The Henry Hub cash bonus payment provision is accounted for as a derivative instrument and recorded at its estimated fair value using a Monte Carlo simulation model. Significant inputs used in the fair value measurement include NYMEX Henry Hub natural gas futures prices as of the date of valuation, the targeted in-service date for the MVP, risk-free interest rates based on U.S. Treasury rates, expected volatility of NYMEX Henry Hub natural gas futures prices and an estimated credit spread of EQT. The expected volatility of NYMEX Henry Hub natural gas futures prices used in the valuation methodology represents a significant unobservable input causing the Henry Hub cash bonus payment provision to be designated as a Level 3 fair value measurement. An expected average volatility of approximately 50% was utilized in the valuation model, which is based on market-quoted volatilities of relevant NYMEX Henry Hub natural gas forward prices. As of March 31, 2022 and December 31, 2021, the fair values of the Henry Hub cash bonus payment provision were $58.1 million and $51.6 million, respectively, which were recorded in other assets on the Company's consolidated balance sheets. During the three months ended March 31, 2022 and 2021, the Company recognized gains of $6.4 million and $7.1 million, respectively, representing the

change in estimated fair value of the derivative instrument during the respective period. The gains are reflected in other income, net in the Company's statements of consolidated comprehensive income.

Other Financial Instruments. The carrying values of cash and cash equivalents, accounts receivable, amounts due to/from related parties and accounts payable approximate fair value due to the short maturity of the instruments; as such, their fair values are Level 1 fair value measurements. The carrying values of borrowings under the Amended EQM Credit Facility, the Former Eureka Credit Facility (prior to its termination), the 2021 Eureka Credit Facility and the Amended 2019 EQM Term Loan Agreement (prior to its termination) approximate fair value as the interest rates are based on prevailing market rates; these are considered Level 1 fair value measurements. As EQM's borrowings under its senior notes are not actively traded, their fair values are estimated using an income approach model that applies a discount rate based on prevailing market rates for debt with similar remaining time-to-maturity and credit risk; as such, their fair values are Level 2 fair value measurements. As of March 31, 2022, and December 31, 2021, the estimated fair values of EQM's senior notes were approximately $6,425.6 million and $7,060.5 million, respectively. The fair value of the Preferred Interest is a Level 3 fair value measurement and is estimated using an income approach model that applies a market-based discount rate. As of March 31, 2022, and December 31, 2021, the estimated fair values of the Preferred Interest were approximately $107.6 million and $117.0 million, respectively, and the carrying values of the Preferred Interest were approximately $98.5 million and $100.0 million, respectively.

8. Earnings Per Share

The Company excluded 30,137 and 30,076 (in thousands) of weighted average anti-dilutive securities related to the Equitrans Midstream Preferred Shares and stock-based compensation awards from the computation of diluted weighted average common shares outstanding for the three months ended March 31, 2022 and 2021, respectively.

The Company grants Equitrans Midstream phantom units to certain non-employee directors that will be paid in Equitrans Midstream common stock upon the director's termination of service on the Board. As there are no remaining service, performance or market conditions related to these awards, 642 and 486 (in thousands) Equitrans Midstream phantom units were included in the computation of basic and diluted weighted average common shares outstanding for the three months ended March 31, 2022 and 2021, respectively.

9. Income Taxes

The Company's effective tax rate was 5.6% for the three months ended March 31, 2022, compared to 21.0% for the three months ended March 31, 2021. For the three months ended March 31, 2022 and 2021, the Company calculated the provision for income taxes for interim periods by applying an estimate of the annual effective tax rate for the full fiscal year to "ordinary" income or loss (pre-tax income or loss excluding unusual or infrequently occurring items) for the periods. The effective tax rate was lower for the three months ended March 31, 2022 compared to the three months ended March 31, 2021 primarily due to a reduction in the valuation allowances that limit tax benefits for the Company’s federal and state deferred tax assets, which valuation allowances were recorded by the Company at December 31, 2021. The effective tax rate for the three months ended March 31, 2022 was lower than the statutory rate primarily due to the reduction in the valuation allowances that limit tax benefits for the Company’s federal and state deferred tax assets. The effective tax rate for the three months ended March 31, 2021 was lower than the statutory rate primarily due to the impact of AFUDC - equity on the MVP project.

For the three months ended March 31, 2022, the Company believes that it is more likely than not that the benefit from a portion of its federal and state net operating loss (NOL) carryforwards and deferred tax assets related to interest disallowance under Internal Revenue Code Section 163(j), net of offsetting deferred tax liabilities, will not be realized. For the three months ended March 31, 2022, the Company recorded a $23.1 million income tax benefit related to changes in valuation allowances because of decreases in federal and state deferred tax assets. As of March 31, 2022, the valuation allowances related to federal and state deferred tax assets that are not more likely than not to be realized were $74.5 million compared to the year ended December 31, 2021, of $97.6 million.

Valuation allowances are recorded to reduce deferred tax assets when it is more likely than not (greater than 50%) that a tax benefit will not be realized. In evaluating the need for a valuation allowance, management considers available evidence, both positive and negative, including potential sources of taxable income, income available in carry-back periods, future reversals of taxable temporary differences, projections of taxable income and income from tax planning strategies. Positive evidence includes reversing temporary differences and projection of future profitability within the carry-forward period, including from tax planning strategies. Negative evidence includes historical pre-tax book losses and Pennsylvania NOL expirations. A review of positive and negative evidence regarding these tax benefits resulted in the conclusion that valuation allowances on the Company’s federal and state NOL carryforwards and deferred tax assets related to interest disallowance under Internal Revenue Code Section 163(j), net of offsetting deferred tax liabilities, were warranted as it was more likely than not that these assets will not be realized. Any determination to change the valuation allowance would impact the Company's income tax expense in the period in which such a determination is made.

Table of Contents

10. Subsequent Events

On April 22, 2022 (the Amendment Date), EQM entered into an amendment (the Third Amendment) to the Amended EQM Credit Facility. The Third Amendment, among other things:

•Replaced LIBOR with SOFR as the benchmark rate for borrowings, including a credit spread adjustment of 0.10% for all applicable interest periods as well as for daily swing line borrowings.

•Extended the stated maturity date, with such extension only applicable for the lenders approving the Third Amendment, from October 31, 2023 (the Earlier Maturity Date) to April 30, 2025 (the Later Maturity Date).

•Reduced the aggregate commitments available under the Amended EQM Credit Facility, as amended by the Third Amendment, on a non-pro rata basis to approximately $2.16 billion, with approximately $1.55 billion in aggregate commitments available under the Amended EQM Credit Facility, as amended by the Third Amendment, on and after the Earlier Maturity Date and prior to the Later Maturity Date.

•Amended the definition of “Applicable Rate” to change the applicable percentages per annum set forth in the “Pricing Grid” for certain pricing levels, which continue to be determined on the basis of EQM’s then current credit ratings. As of the Amendment Date, (i) Base Rate Loans (as defined in the Amended EQM Credit Facility, as amended by the Third Amendment) bear interest at a base rate plus a margin of 1.750% per annum, (ii) SOFR Loans (as defined in the Amended EQM Credit Facility, as amended by the Third Amendment) bear interest at Adjusted Term SOFR (as defined in the Amended EQM Credit Facility, as amended by the Third Amendment) plus a margin of 2.750% per annum, (iii) Daily Simple Swing Line Loans (as defined in the Amended EQM Credit Facility, as amended by the Third Amendment) bear interest at Adjusted Daily Simple SOFR (as defined in the Amended EQM Credit Facility, as amended by the Third Amendment) plus a margin of 2.750% per annum, (iv) the letter of credit fee payable on the daily maximum amount available under each letter of credit is 2.750% per annum and (v) the commitment fee payable for unused commitments is 0.500% per annum.

•Amended the financial covenant, such that the Consolidated Leverage Ratio (as defined in the Amended EQM Credit Facility, as amended by the Third Amendment) as at the end of each fiscal quarter of EQM ending on or after the Amendment Date cannot exceed 5.50 to 1.00; provided that, effective as of the MVP Mobilization Effective Date (as defined in the Amended EQM Credit Facility, as amended by the Third Amendment), the maximum Consolidated Leverage Ratio permitted with respect to the end of the fiscal quarter in which the MVP Mobilization Effective Date occurs and the end of each of the three consecutive fiscal quarters of EQM thereafter shall be 5.85 to 1.00.

•Reduced each of the general lien and general subsidiary debt baskets based on Consolidated Net Tangible Assets (as defined in the Amended EQM Credit Facility, as amended by the Third Amendment) from 5.0% to 2.5% of Consolidated Net Tangible Assets.

•Added a borrowing condition requiring that, solely to the extent a credit extension is used to repay, redeem or refinance EQM’s senior notes, total outstanding amounts under the Amended EQM Credit Facility, as amended by the Third Amendment, must not exceed 85% of the aggregate commitments after giving effect to the use of proceeds.

Table of Contents

EQUITRANS MIDSTREAM CORPORATION

Item 2. Management's Discussion and Analysis of Financial Condition and Results of Operations

You should read the following discussion and analysis of financial condition and results of operations in conjunction with the consolidated financial statements, and the notes thereto, included elsewhere in this report.

Cautionary Statements

Disclosures in this Quarterly Report on Form 10-Q contain certain forward-looking statements within the meaning of Section 21E of the Securities Exchange Act of 1934, as amended (the Exchange Act), and Section 27A of the Securities Act of 1933, as amended (the Securities Act). Statements that do not relate strictly to historical or current facts are forward-looking and usually identified by the use of words such as "anticipate," "estimate," "could," "would," "will," "may," "forecast," "approximate," "expect," "project," "intend," "plan," "believe," "target" and other words of similar meaning in connection with any discussion of future operating or financial matters. Without limiting the generality of the foregoing, forward-looking statements contained in this Quarterly Report on Form 10-Q include the matters discussed in the section captioned "Outlook" in Part I, "Item 2. Management's Discussion and Analysis of Financial Condition and Results of Operations," and the expectations of plans, strategies, objectives, and growth and anticipated financial and operational performance of Equitrans Midstream Corporation (together with its subsidiaries, Equitrans Midstream or the Company), including:

•guidance and any changes in such guidance regarding the Company’s gathering, transmission and storage and water services revenue and volume, including the anticipated effects associated with the EQT Global GGA and related documents entered into with EQT;

•projected revenue (including from firm reservation fees) and volumes, deferred revenues, expenses and contract liabilities, and the effects on liquidity, leverage, projected revenue, deferred revenue and contract liabilities associated with the EQT Global GGA and the MVP project (including changes in the targeted full in-service date for such project);

•the ultimate gathering fee relief, and timing thereof, provided to EQT under the EQT Global GGA and related agreements, including the exercise by EQT of any cash-out option as an alternative to receiving a portion of such relief;

•the Company's ability to de-lever;

•the weighted average contract life of gathering, transmission and storage contracts;

•infrastructure programs (including the timing, cost, capacity and sources of funding with respect to gathering, transmission and storage and water projects);

•the cost to construct or restore right-of-way for, capacity, shippers for, timing and durability of regulatory approvals and concluding litigation, final design (including expansions, extensions or refinements and capital related thereto), ability to contract additional capacity on, mitigate emissions from and complete, and targeted in-service dates of current or in-service projects or assets, in each case as applicable;

•the ultimate terms, partner relationships and structure of the MVP Joint Venture and ownership interests therein;

•the impact of changes in the targeted full in-service date of the MVP project on, among other things, the fair value of the Henry Hub cash bonus payment provision of the EQT Global GGA and the estimated transaction price allocated to the Company's remaining performance obligations under certain contracts with firm reservation fees and MVCs;

•expansion projects in the Company's operating areas and in areas that would provide access to new markets;

•the Company's ability to provide produced and mixed water handling services and realize expansion opportunities;

•the Company's ability to identify and complete acquisitions and other strategic transactions, including joint ventures, effectively integrate transactions into the Company's operations, and achieve synergies, system optionality, accretion and other benefits associated with transactions, including through increased scale;

•any credit rating impacts associated with the MVP project, customer credit ratings changes, defaults, acquisitions, dispositions and financings and any changes in EQM's credit ratings;

Table of Contents

•the effect and outcome of future contractual disputes, litigation and other proceedings, including regulatory proceedings;

•the effects of any consolidation of or effected by upstream gas producers, whether in or outside of the Appalachian Basin;

•the timing and amount of future issuances or repurchases of the Company's securities;

•the effects of conversion, if at all, of the Equitrans Midstream Preferred Shares (as defined herein);

•the effects of seasonality;

•expected cash flows and MVCs, including those associated with the EQT Global GGA, and the potential impacts thereon of the commission timing and cost of the MVP project;

•the ability to achieve, and time for achieving, Hammerhead pipeline full commercial in-service;

•projected capital contributions and capital and operating expenditures, including the amount and timing of reimbursable capital expenditures, capital budget and sources of funds for capital expenditures;

•the Company's potential seeking recoupment of, and ability to recoup, replacement and related costs;

•dividend amounts, timing and rates;

•changes in commodity prices and the effect of commodity prices on the Company's business;

•future decisions of customers in respect of curtailing natural gas production, timing of turning wells in line, rig and completion activity and related impacts on the Company's business;

•liquidity and financing requirements, including sources and availability;

•interest rates;

•the ability of the Company's subsidiaries (some of which are not wholly owned) to service debt under, and comply with the covenants contained in, their respective credit agreements;

•expectations regarding natural gas and water volumes in the Company's areas of operations;

•the Company's ability to achieve anticipated benefits associated with the execution of the EQT Global GGA and other commercial agreements;

•the impact on the Company and its subsidiaries of the coronavirus disease 2019 (COVID-19) pandemic;

•the Company's ability to achieve, and create value from, its environmental, social and governance (ESG) and sustainability targets (including targets set forth in its climate policy) and the Company's ability to respond, and impacts of responding, to increasing stakeholder scrutiny in these areas;

•the effectiveness of the Company's information technology systems and practices to defend against evolving cyberattacks on United States critical infrastructure;

•the effects of government regulation including any quantification of potential impacts of regulatory matters related to climate change on the Company; and

•tax status and position.

The forward-looking statements included in this Quarterly Report on Form 10-Q involve risks and uncertainties that could cause actual results to differ materially from projected results. Accordingly, investors should not place undue reliance on forward-looking statements as a prediction of actual results. The Company has based these forward-looking statements on management's current expectations and assumptions about future events. While the Company considers these expectations and assumptions to be reasonable, they are inherently subject to significant business, economic, competitive, regulatory, judicial and other risks and uncertainties, many of which are difficult to predict and are beyond the Company's control. The risks and uncertainties that may affect the operations, performance and results of the Company's business and forward-looking statements include, but are not limited to, those set forth under "Item 1A. Risk Factors" in the Company's Annual Report on Form 10-K for the year ended December 31, 2021, as updated by this Quarterly Report on Form 10-Q.

Table of Contents

Any forward-looking statement speaks only as of the date on which such statement is made and the Company does not intend to correct or update any forward-looking statement, unless required by securities law, whether as a result of new information, future events or otherwise.

Table of Contents

Executive Overview

Net income attributable to Equitrans Midstream common shareholders was $86.5 million ($0.20 per diluted share) for the three months ended March 31, 2022 compared to $58.1 million ($0.13 per diluted share) for the three months ended March 31, 2021. The increase resulted primarily from the loss on debt extinguishment in the first quarter of 2021, lower income tax expense and lower operating expenses in the first quarter of 2022, partially offset by lower operating revenues in the first quarter of 2022.

COVID-19 Update

Effective April 4, 2022, given, among other things, modifications in guidelines from the U.S. Centers for Disease Control and Prevention, the Company terminated its mandatory work-from-home protocol, commenced its return-to-office plan for its office-based employees and made adjustments to certain of its other companywide working protocols which had been responsive to the COVID-19 outbreak. However, the Company acknowledges that the COVID-19 pandemic is still ongoing. Although the outbreak has had, and continues to have, minimal direct impact on the Company’s overall operations, the Company cannot predict that the pandemic, or further developments regarding variants of COVID-19 or related governmental action, will not have any impact in the future on the Company's business, results of operations or financial position. For further information regarding the potential impact of COVID-19 on the Company, see "The ongoing outbreak of COVID-19 and its variant strains (or any future pandemic) could harm our business, results of operations and financial condition." under "Item 1A. Risk Factors" in the Company’s Annual Report on Form 10-K for the year ended December 31, 2021.

Business Segment Results

Operating segments are revenue-producing components of an enterprise for which separate financial information is produced internally and is subject to evaluation by the chief operating decision maker in deciding how to allocate resources. Headquarters costs consist primarily of certain unallocated corporate expenses and transaction costs, as applicable. Net interest expense, components of other income and income tax expense (benefit) are managed on a consolidated basis. The Company has presented each segment's operating income (loss), unrealized gain on derivative instruments, equity income, impairment of equity method investment and various operational measures, as applicable, in the following sections. Management believes that the presentation of this information is useful to management and investors regarding the financial condition, results of operations and trends and uncertainties of its segments. The Company has reconciled each segment's operating income (loss) to the Company's consolidated operating income and net income (loss) in Note 2 to the consolidated financial statements.

Table of Contents

Gathering Results of Operations


	Three Months Ended March 31,
		2022		2021		% Change
		(Thousands, except per day amounts)
FINANCIAL DATA
Firm reservation fee revenues (a)		$	132,597	$	148,192	(10.5)



Volumetric-based fee revenues (b)		87,193		101,884		(14.4)
Total operating revenues		219,790		250,076		(12.1)
Operating expenses:
Operating and maintenance		22,175		22,666		(2.2)
Selling, general and administrative		17,534		24,804		(29.3)

Depreciation		48,255		46,547		3.7
Amortization of intangible assets		16,205		16,205		—

Total operating expenses		104,169		110,222		(5.5)
Operating income		$	115,621	$	139,854	(17.3)

Other income, net (c)		$	6,442	$	7,135	(9.7)

OPERATIONAL DATA
Gathered volumes (BBtu per day)
Firm capacity (d)		5,256		5,244		0.2
Volumetric-based services		2,737		3,345		(18.2)
Total gathered volumes		7,993		8,589		(6.9)

Capital expenditures (e)		$	53,147	$	48,113	10.5

(a)For the three months ended March 31, 2022 and 2021, firm reservation fee revenues included approximately $2.7 million and $3.2 million, respectively, of MVC unbilled revenues.

(b)For the three months ended March 31, 2021, volumetric-based fee revenues included approximately $6.2 million of unbilled revenues.

(c)Other income, net includes the unrealized gains on derivative instruments associated with the Henry Hub cash bonus payment provision. See Note 7 to the consolidated financial statements for further information.

(d)Includes volumes up to the contractual MVC under agreements structured with MVCs. Volumes in excess of the contractual MVC are reported under Volumetric-based services.

(e)Includes approximately $3.0 million and $1.7 million of capital expenditures related to the noncontrolling interest in Eureka Midstream for the three months ended March 31, 2022 and 2021, respectively.

Three Months Ended March 31, 2022 Compared to Three Months Ended March 31, 2021

Gathering operating revenues decreased by $30.3 million for the three months ended March 31, 2022 compared to the three months ended March 31, 2021. Firm reservation fee revenues decreased by $15.6 million primarily due to higher deferred revenue primarily resulting from assumption changes in the fourth quarter of 2021 associated with certain potential contract extensions impacting the estimated total consideration under the EQT Global GGA. Volumetric-based fee revenues decreased by $14.7 million primarily due to lower gathered volumes resulting from normal well declines and reduced producer activity.

Gathering operating expenses decreased by $6.1 million for the three months ended March 31, 2022 compared to the three months ended March 31, 2021. Selling, general and administrative expenses decreased by $7.3 million primarily due to lower professional fees and personnel costs, partially offset by an increase in depreciation expense of $1.7 million as a result of additional assets placed in-service.

See also “Outlook” for discussions of the EQT Global GGA and the transactions related thereto, including the gathering fee relief to EQT thereunder. The Company expects that the revenues resulting from the MVCs under the EQT Global GGA will increase the proportion of the Company's total operating revenues that are firm reservation fee revenues, and correspondingly decrease the portion of the Company's total operating revenues that are volumetric-based fee revenues, in future periods. Firm reservation fee revenues under the Company’s Hammerhead gathering agreement with EQT also are expected to contribute to

Table of Contents

an increase in the Company’s firm reservation fee revenues following achievement of the Hammerhead pipeline full commercial in-service. See also "Outlook" for discussions of the expected timing of the Hammerhead pipeline in service.

Transmission Results of Operations


	Three Months Ended March 31,
		2022		2021		% Change
		(Thousands, except per day amounts)
FINANCIAL DATA
Firm reservation fee revenues		$	102,870	$	101,389	1.5



Volumetric-based fee revenues		7,925		10,030		(21.0)
Total operating revenues		110,795		111,419		(0.6)
Operating expenses:
Operating and maintenance		3,933		7,282		(46.0)
Selling, general and administrative		8,406		8,849		(5.0)
Depreciation		13,894		13,800		0.7
Total operating expenses		26,233		29,931		(12.4)
Operating income		$	84,562	$	81,488	3.8

Equity income		$	4	$	3	33.3

OPERATIONAL DATA
Transmission pipeline throughput (BBtu per day)
Firm capacity reservation		3,151		2,937		7.3
Volumetric-based services		41		9		355.6
Total transmission pipeline throughput		3,192		2,946		8.4

Average contracted firm transmission reservation commitments (BBtu per day)		4,487		4,424		1.4

Capital expenditures (a)		$	4,226	$	3,505	20.6

(a)Transmission capital expenditures do not include aggregate capital contributions made to the MVP Joint Venture for the MVP and MVP Southgate projects of approximately $72.5 million and $10.7 million for the three months ended March 31, 2022 and 2021, respectively.

Three Months Ended March 31, 2022 Compared to Three Months Ended March 31, 2021

Transmission operating revenues decreased by $0.6 million for the three months ended March 31, 2022 compared to the three months ended March 31, 2021 primarily as a result of decreased volumetric-based fee revenues due to lower storage activities, partially offset by an increase in firm reservation fee revenues primarily due to higher contracted firm transmission capacity and rates.

Operating expenses decreased by $3.7 million for the three months ended March 31, 2022 compared to the three months ended March 31, 2021 primarily as a result of lower operating and maintenance expense due to operational efficiencies.

Equity income was relatively flat for the three months ended March 31, 2022 compared to the three months ended March 31, 2021.

The Company's equity income in future periods will be affected by the timing of the resumption of the remaining MVP project growth construction activities and associated AFUDC, and the timing of the completion of the MVP project, and such impact could continue to be substantial.

Table of Contents

Water Results of Operations


	Three Months Ended March 31,
		2022		2021		% Change
		(Thousands, except MMgal amounts)
FINANCIAL DATA
Firm reservation fee revenues (a)		$	5,752	$	1,844	211.9
Volumetric-based fee revenues		5,809		16,657		(65.1)
Total operating revenues		11,561		18,501		(37.5)
Operating expenses:
Operating and maintenance		6,709		4,135		62.2
Selling, general and administrative		2,191		1,714		27.8
Depreciation		4,517		8,175		(44.7)

Total operating expenses		13,417		14,024		(4.3)
Operating (loss) income		$	(1,856)	$	4,477	(141.5)

OPERATIONAL DATA
Water services volumes (MMgal)
Firm capacity reservation (b)		110		36		205.6
Volumetric-based services		208		380		(45.3)
Total water volumes		318		416		(23.6)

Capital expenditures		$	9,565	$	4,807	99.0

(a) For the three months ended March 31, 2021, firm reservation fee revenues included approximately $0.5 million of MVC unbilled revenues.

(b) Includes volumes up to the contractual MVC under agreements structured with MVCs or ARCs, as applicable. Volumes in excess of the contractual MVC are reported under Volumetric-based services.

Three Months Ended March 31, 2022 Compared to Three Months Ended March 31, 2021

Water operating revenues decreased by $6.9 million for the three months ended March 31, 2022 compared to the three months ended March 31, 2021. Firm reservation fee revenues increased by $3.9 million primarily as a result of increased revenues associated with ARCs. Volumetric-based fee revenues decreased $10.8 million primarily due to lower volumes and rates.

Water operating expenses decreased by $0.6 million for the three months ended March 31, 2022 compared to the three months ended March 31, 2021. Depreciation expense decreased due to the impairments of certain long-lived assets during the second quarter of 2021, which was partly offset by higher operating and maintenance expense primarily due to higher water transfer and water line expense.

The Company’s water services are directly associated with producers’ well completion activities and fresh and produced water needs (which are primarily driven by horizontal lateral lengths and the number of completion stages per well). Therefore, the Water operating results traditionally fluctuate from year-to-year in response to producers’ well completion activities. The

Company expects Water operating revenues to be higher for the year ending December 31, 2022 as compared to the year ended

December 31, 2021 primarily due to the 2021 Water Services Agreement that became effective on March 1, 2022.

The Company also expects that the contractual revenues resulting from the ARC under the 2021 Water Services Agreement will increase the proportion of the Company's total water operating revenues that are firm reservation fee revenues, and correspondingly decrease the portion of the Company's total water operating revenues that are volumetric-based fee revenues, in future periods. See "Outlook" for further discussion of the 2021 Water Services Agreement.

Other Income Statement Items

Other Income, Net

Other income, net decreased $1.3 million for the three months ended March 31, 2022 compared to the three months ended March 31, 2021. The decrease was primarily due to a $0.7 million decrease in unrealized gain on derivative instruments

Table of Contents

associated with the Henry Hub cash bonus payment provision due to the impact of changes in the targeted in-service date for the MVP project, partially offset by an increase in NYMEX Henry Hub natural gas futures prices.

See also "Outlook" for a discussion of factors affecting the estimated fair value of the derivative asset attributable to the Henry Hub cash bonus payment provision that is recognized in other income, net on the Company's statements of consolidated comprehensive income.

Loss on Extinguishment of Debt

Loss on extinguishment of debt decreased $41.0 million for the three months ended March 31, 2022 compared to the three months ended March 31, 2021. During the three months ended March 31, 2021, the Company incurred a loss on the extinguishment of debt of $41.0 million related to the payment of the Tender Offer premium and write off of unamortized discounts and financing costs related to the prepayment of the EQM Term Loans under, and termination of, the Amended 2019 EQM Term Loan Agreement and purchase of 2023 Notes in the Tender Offers. See Note 6 to the consolidated financial statements for additional discussion.

Net Interest Expense

Net interest expense decreased $2.0 million for the three months ended March 31, 2022 compared to the three months ended March 31, 2021 primarily due to lower interest expense of $1.9 million primarily associated with lower borrowings and commitment fees on the Amended EQM Credit Facility.

See also Note 6 and Note 10 to the consolidated financial statements for a discussion of certain of the Company's outstanding debt.

Income Taxes

See Note 9 to the consolidated financial statements for an explanation of the changes in income taxes for the three months ended March 31, 2022 compared to the three months ended March 31, 2021.

Management continues to evaluate the need for valuation allowances on the Company's deferred tax assets. Management expects the reduction of valuation allowances to continue during the year ended December 31, 2022 based on its estimated annual effective tax rate. The Company's estimated annual effective tax rate is susceptible to change, including the amount of valuation allowances realized, and such impact may be substantial.

Net Income Attributable to Noncontrolling Interests

Net income attributable to noncontrolling interests was relatively flat for the three months ended March 31, 2022 compared to the three months ended March 31, 2021.

Capital Expenditures

See "Investing Activities" and "Capital Requirements" under "Capital Resources and Liquidity" for discussion of capital expenditures and capital contributions.

Outlook

The Company's strategically-located assets overlay core acreage in the Appalachian Basin. The location of the Company's assets allows its producer customers to access major demand markets in the U.S. The Company is one of the largest natural gas gatherers in the U.S. and its largest customer, EQT, was one of the largest natural gas producers in the U.S. based on average daily sales volumes as of March 31, 2022 and EQT's public senior debt had investment grade credit ratings from Standard & Poor's Global Ratings and Fitch Ratings as of that date. The Company maintains a stable cash flow profile, with approximately 71% of its revenue for the three months ended March 31, 2022 generated by firm reservation fees. Further, the percentage of the Company's operating revenues that are generated by firm reservation fees is expected to increase in future years as a result of the 15-year term EQT Global GGA, which includes an MVC of 3.0 Bcf per day that became effective on April 1, 2020 and gradually steps up to 4.0 Bcf per day through December 2031 following the full in-service date of the MVP. This contract structure enhances the stability of the Company's cash flows and limits its exposure to customer volume variability.

The Company's principal strategy is to achieve greater scale and scope, enhance the durability of its financial strength and to continue to work to position itself for a lower carbon economy, which the Company expects will drive future growth and investment. The Company is implementing its strategy by leveraging its existing assets, executing on its growth projects (including through potential expansion and extension opportunities), periodically evaluating strategically-aligned inorganic

Table of Contents

growth opportunities (whether within its existing footprint or to extend the Company's reach into the southeast United States and to become closer to key demand markets, such as the Gulf of Mexico LNG export market), and focusing on ESG and sustainability-oriented initiatives. Additionally, the Company is also continuing to focus on strengthening its balance sheet through:

•highly predictable cash flows backed by firm reservation fees;

•actions to de-lever its balance sheet;

•disciplined capital spending;

•operating cost control; and

•an appropriate dividend policy.

As part of its approach to organic growth, the Company is focused on its projects and assets outlined below, many of which are supported by contracts with firm capacity, MVC or ARC commitments.

The Company expects that the MVP project (should it be placed in-service), together with the Hammerhead pipeline and Equitrans, L.P. Expansion Project (EEP), will primarily drive the Company's organic growth, as discussed in further detail below.

•Mountain Valley Pipeline. The MVP is being constructed by a joint venture among the Company and affiliates of each of NextEra Energy, Inc., Consolidated Edison, Inc. (Con Edison), AltaGas Ltd. and RGC Resources, Inc. As of March 31, 2022, the Company owned an approximate 47.0% interest in the MVP project and will operate the MVP. The MVP is an estimated 300-mile, 42-inch diameter natural gas interstate pipeline with a targeted capacity of 2.0 Bcf per day that is designed to span from the Company's existing transmission and storage system in Wetzel County, West Virginia to Pittsylvania County, Virginia, providing access to the growing southeast demand markets. The MVP Joint Venture has secured a total of 2.0 Bcf per day of firm capacity commitments at 20-year terms. Additional shippers have expressed interest in the MVP project and the MVP Joint Venture is evaluating an expansion opportunity that could add approximately 0.5 Bcf per day of capacity through the installation of incremental compression.

In October 2017, the FERC issued the Certificate of Public Convenience and Necessity (the Certificate) for the MVP. In the first quarter of 2018, the MVP Joint Venture received limited notice to proceed with certain construction activities from the FERC and commenced construction. Following a comprehensive review of all outstanding stream and wetland crossings across the approximately 300-mile MVP project route, on February 19, 2021, the MVP Joint Venture submitted (i) a joint application package to each of the Huntington, Pittsburgh and Norfolk Districts of the U.S. Army Corps of Engineers (Army Corps) that requested an Individual Permit from the Army Corps to effect approximately 300 water crossings utilizing open cut techniques (the Army Corps Individual Permit) and (ii) an application to amend the Certificate that sought FERC authority to utilize alternative trenchless construction methods to effect approximately 120 water crossings. On April 8, 2022, the FERC authorized the amended Certificate. Related to seeking the Army Corps Individual Permit, on March 4, 2021, the MVP Joint Venture submitted applications to each of the West Virginia Department of Environmental Protection (WVDEP) and the Virginia Department of Environmental Quality (VADEQ) seeking Section 401 water quality certification approvals or waivers (such approvals or waivers, the State 401 Approvals), which State 401 Approvals were each received in December 2021. As discussed in Part II, "Item 1. Legal Proceedings" of this Quarterly Report on Form 10-Q, on January 25, 2022, the MVP Joint Venture's authorizations related to the Jefferson National Forest (JNF) received from the Bureau of Land Management (BLM) and the U.S. Forest Service (USFS) were vacated and remanded on specific issues by the U.S. Court of Appeals for the Fourth Circuit (Fourth Circuit). As also discussed in Part II, "Item 1. Legal Proceedings" of this Quarterly Report on Form 10-Q, on February 2, 2022, the Fourth Circuit vacated and remanded on specific issues the Biological Opinion and Incidental Take Statement issued by the United States Department of the Interior's Fish and Wildlife Service (FWS) for the MVP project. After evaluating legal options and consulting with the relevant federal agencies, the MVP Joint Venture plans to pursue new authorizations relating to the JNF and a new Biological Opinion and Incidental Take Statement and as a result, the Company is targeting a full in-service date for the MVP project during the second half of 2023 at a targeted total project cost of approximately $6.6 billion (excluding AFUDC).

In addition to timely receiving, and subsequently maintaining, new authorizations in respect of the JNF, and a Biological Opinion and Incidental Take Statement, the MVP Joint Venture must, in order to complete the project, among other things, timely receive the Army Corps Individual Permit (as well as timely receive, if necessary,

Table of Contents

certain other state-level approvals), as well as any necessary extensions from FERC to complete the MVP project. The MVP Joint Venture also must (i) continue to have available the orders previously issued by the FERC, which are the subject of ongoing litigation, modifying its prior stop work orders and extending the MVP Joint Venture’s prescribed time to complete the MVP project; and (ii) timely receive authorization from the FERC to complete construction work in the portion of the project route currently remaining subject to the FERC’s previous stop work order and in the JNF. In each case, any such foregoing or other authorizations, including the FERC's April 2022 order authorizing the amended Certificate, must remain in effect notwithstanding any pending or future challenge thereto. For further information regarding litigation and regulatory related delays affecting the completion of the MVP project, see Part II, "Item 1. Legal Proceedings" of this Quarterly Report on Form 10-Q. See also "The regulatory approval process for the construction of new midstream assets is very challenging, has significantly increased costs and delayed targeted in-service dates, and decisions by regulatory and judicial authorities in pending or potential proceedings are likely to impact our or the MVP Joint Venture's ability to obtain or maintain in effect all approvals and authorizations necessary to complete certain projects on the targeted time frame or at all or our ability to achieve the expected investment returns on the projects." included in "Item 1A. Risk Factors" in the Company's Annual Report on Form 10-K for the year ended December 31, 2021.

On November 4, 2019, Con Edison exercised an option to cap its investment in the construction of the MVP project at approximately $530 million (excluding AFUDC). The Company and NextEra Energy, Inc. are obligated, and RGC Resources, Inc., another member of the MVP Joint Venture owning an interest in the MVP project, has opted, to fund the shortfall in Con Edison's capital contributions on a pro rata basis. Such funding by the Company and funding by other members has and will correspondingly increase the Company's and such other members' respective interests in the MVP project and decrease Con Edison's interest in the MVP project. As a result, based on the Company's total targeted cost for the project of approximately $6.6 billion (excluding AFUDC), the Company's equity ownership in the MVP project will progressively increase from approximately 47.0% to approximately 48.1%.

Through March 31, 2022, based on the MVP project's total targeted cost, the Company had funded approximately $2.6 billion of its estimated total capital contributions of approximately $3.4 billion (inclusive of additional contributions required due to the Con Edison cap described above), which estimated total capital contributions include approximately $180 million in excess of the Company's ownership interest. For 2022, the Company expects to make total capital contributions of approximately $175 million to $225 million primarily related to work completed in late 2021 and ongoing right-of-way maintenance, of which approximately $72.0 million had been contributed to the MVP Joint Venture as of March 31, 2022.

•Wellhead Gathering Expansion Projects and Hammerhead Pipeline. During the three months ended March 31, 2022, the Company invested approximately $53.1 million in gathering projects (inclusive of capital expenditures related to the noncontrolling interest in Eureka Midstream). For 2022, the Company expects to invest approximately $270 million to $320 million in gathering projects (inclusive of expected capital expenditures of approximately $20 million related to the noncontrolling interest in Eureka Midstream). The primary projects include infrastructure expansion of core development areas in the Marcellus and Utica Shales in southwestern Pennsylvania, southeastern Ohio and northern West Virginia for EQT, Range Resources Corporation (Range Resources) and other producers.

The Hammerhead pipeline is a 1.6 Bcf per day gathering header pipeline that is primarily designed to connect natural gas produced in Pennsylvania and West Virginia to the MVP, Texas Eastern Transmission and Dominion Transmission, is supported by a 20-year term, 1.2 Bcf per day, firm capacity commitment from EQT and cost approximately $540 million. The Company expects Hammerhead pipeline full commercial in-service to commence in conjunction with full MVP in-service.

•Transmission Projects and Equitrans Expansion Project. During the three months ended March 31, 2022, the Company invested approximately $4.2 million in transmission projects, including the EEP. The EEP is designed to provide north-to-south capacity on the mainline Equitrans, L.P. system, including primarily for deliveries to the MVP. A portion of the EEP commenced operations with interruptible service in the third quarter of 2019. The EEP provides capacity of approximately 600 MMcf per day and offers access to several markets through interconnects with Texas Eastern Transmission, Dominion Transmission and Columbia Gas Transmission. Once the MVP is fully placed in service, firm transportation agreements for 550 MMcf per day of capacity will commence under 20-year terms.

For 2022, the Company expects to invest approximately $45 million in transmission projects, inclusive of capital expenditures expected for 2022 associated with the Company's Ohio Valley Connector expansion project

Table of Contents

(OVCX). OVCX will increase deliverability on the Company's existing Ohio Valley Connector pipeline (OVC) by approximately 350 MMcf per day, create new receipt and delivery transportation paths, and enhance long-term reliability. The project is supported by new long-term firm capacity commitments of 330 MMcf per day, as well as an extension of approximately 1.0 Bcf per day of existing contracted mainline capacity for EQT. OVCX is designed to meet growing demand in key markets in the mid-continent and gulf coast through existing interconnects with long-haul pipelines in Clarington, Ohio. The targeted in-service date for the incremental OVC capacity is the third quarter of 2023. The Company expects to invest approximately $160 million, which includes approximately $130 million for new compression. The project is consistent with the Company's ongoing efforts to optimize existing assets and achieve capital efficiency.

•MVP Southgate Project. In April 2018, the MVP Joint Venture announced the MVP Southgate project, which is a proposed 75-mile interstate pipeline that is contemplated to extend from the MVP at Pittsylvania County, Virginia to new delivery points in Rockingham and Alamance Counties, North Carolina. The MVP Southgate project is backed by a 300 MMcf per day firm capacity commitment from Dominion Energy North Carolina, and, as currently designed, reflects potential expansion capabilities that could provide up to 900 MMcf per day of total capacity. The Company is expected to operate the MVP Southgate project and owned a 47.2% interest in the MVP Southgate project as of March 31, 2022.

The MVP Joint Venture submitted the MVP Southgate certificate application to the FERC in November 2018. The Final Environmental Impact Statement for the MVP Southgate project was issued on February 14, 2020. In June 2020, the FERC issued the Certificate of Public Convenience and Necessity for the MVP Southgate; however, the FERC, while authorizing the project, directed the Office of Energy Projects not to issue a notice to proceed with construction until necessary federal permits are received for the MVP project and the Director of the Office of Energy Projects lifts the stop work order and authorizes the MVP Joint Venture to continue constructing the MVP project. On August 11, 2020, the North Carolina Department of Environmental Quality (NCDEQ) denied the MVP Southgate project's application for a Clean Water Act Section 401 Individual Water Quality Certification and Jordan Lake Riparian Buffer Authorization due to uncertainty surrounding the completion of the MVP project. On March 11, 2021, the Fourth Circuit, pursuant to an appeal filed by the MVP Joint Venture, vacated the NCDEQ's denial and remanded the matter to the NCDEQ for additional review. On April 29, 2021, the NCDEQ reissued its denial of the MVP Southgate project's application for a Clean Water Act Section 401 Individual Water Quality Certification and Jordan Lake Riparian Buffer Authorization. On December 3, 2021, the Virginia State Air Pollution Control Board denied the permit for the MVP Southgate project’s Lambert compressor station, which decision the MVP Joint Venture initially appealed before withdrawing its request to review the denial. See the discussion of litigation and regulatory related delays affecting the completion of the MVP Southgate project set forth in Part II, "Item 1. Legal Proceedings" of this Quarterly Report on Form 10-Q.

Given the continually evolving regulatory and legal environment for greenfield pipeline construction projects, as well as factors specific to the MVP and MVP Southgate projects, including the December 2021 compressor station state air permit denial, the MVP Joint Venture continues to evaluate the MVP Southgate project, including engaging in discussions with Dominion Energy North Carolina regarding options with respect to the MVP Southgate project, including potentially refining the project’s design and timing in lieu of pursuing the project as originally contemplated. Dominion Energy North Carolina’s obligations under the precedent agreement in support of the original project are subject to certain conditions, including that the MVP Joint Venture complete construction of the project facilities by June 1, 2022, which deadline is subject to extension by virtue of previously declared events of force majeure. The Company is unable to predict the results of the discussions between the MVP Joint Venture and Dominion Energy North Carolina, including any potential modifications to the project, or ultimate undertaking or completion of the project.

The MVP Southgate project, as originally designed, was estimated to cost a total of approximately $450 million to $500 million, a portion of which the Company expected to fund. For 2022, the Company expects to make capital contributions of approximately $5 million to the MVP Joint Venture for the MVP Southgate project, of which approximately $0.5 million had been contributed as of March 31, 2022.

•Water Operations. During the three months ended March 31, 2022, the Company invested approximately $9.6 million in its water infrastructure. In 2022, the Company expects to invest approximately $75 million to complete the initial mixed-use water system buildout. This includes approximately $20 million to replace certain previously installed water lines that the Company believes do not meet their prescribed quality standards. The Company intends to seek recoupment of such replacement and related costs.

Table of Contents

See further discussion of capital expenditures in the "Capital Requirements" section below.

EQT Global GGA. On February 27, 2020, the Company announced the EQT Global GGA, which is a 15-year contract that includes, among other things, a 3.0 Bcf per day MVC (which gradually steps up to 4.0 Bcf per day through December 2031 following the full in-service date of the MVP) and the dedication of a substantial majority of EQT’s core acreage in southwestern Pennsylvania and West Virginia to the Company. Under the EQT Global GGA, EQT will receive certain gathering fee relief over a period of three years, subject to any exercise of the EQT Cash Option (as further described below). The EQT Global GGA replaced 14 previous gathering agreements between EQT and the Company.

Under the EQT Global GGA, the performance obligation is to provide daily MVC capacity and as such the total consideration is allocated proportionally to the daily MVC over the life of the contract. In periods that the gathering MVC revenue billed will exceed the allocated consideration, the excess will be deferred to the contract liability and recognized in revenue when the performance obligation has been satisfied. While the 3.0 Bcf per day MVC capacity became effective on April 1, 2020, additional daily MVC capacity and the associated gathering MVC fees payable by EQT to the Company as set forth in the EQT Global GGA are conditioned upon the full in-service date of the MVP. There are ongoing legal and regulatory matters that affect the MVP project which have had and/or could have (as applicable) a material effect on the performance obligation, the allocation of the total consideration over the life of the contract and the gathering MVC fees payable by EQT under the contract.

The gathering MVC fees payable by EQT to the Company are subject to potential reductions for certain contract years as set forth in the EQT Global GGA, conditioned to begin the first day of the quarter in which the full in-service date of the MVP occurs, which provide for estimated aggregate fee relief of approximately $270 million in the first twelve-month period, approximately $230 million in the second twelve-month period and approximately $35 million in the third twelve-month period. Further, the EQT Global GGA provides for a fee credit to the gathering rate for certain gathered volumes that also receive separate transmission services under certain transmission contracts. In addition, given that the MVP full in-service date did not occur by January 1, 2022, EQT has an option until December 31, 2022, to forgo approximately $145 million of the gathering fee relief in such first twelve-month period and approximately $90 million of the gathering fee relief in such second twelve-month period in exchange for a cash payment from the Company to EQT in the amount of approximately $196 million (the EQT Cash Option).

Based on the Henry Hub natural gas forward strip prices as of April 29, 2022 and the terms of the Henry Hub cash bonus payment provision, any further delays in the full in-service date for the MVP project, including beyond the most recent targeted full in-service date of the second half of 2023, would decrease the estimated fair value of the derivative asset attributable to the Henry Hub cash bonus payment provision, and such decrease may be substantial. For a discussion of the potential effect of hypothetical changes to the NYMEX Henry Hub natural gas future prices on the estimated fair value of the derivative asset attributable to the Henry Hub cash bonus payment provision, see "Commodity Prices" in Part I, "Item 3. Quantitative and Qualitative Disclosures About Market Risk" of this Quarterly Report on Form 10-Q. Changes in estimated fair value are recognized in other income, net, on the Company’s statements of consolidated comprehensive income.

2021 Water Services Agreement. On October 22, 2021, the Company and EQT entered into a new 10-year, mixed-use water services agreement covering operations within a dedicated area in southwestern Pennsylvania. The 2021 Water Services Agreement became effective on March 1, 2022 and replaced the Water Services Letter Agreement and certain other existing Pennsylvania water services agreements. Pursuant to the 2021 Water Services Agreement, EQT has agreed to pay the Company a minimum ARC for water services equal to $40 million in each of the first five years of the 10-year contract term and equal to $35 million per year for the remaining five years of the contract term.

For further discussion of the Company's commercial relationship with EQT and related considerations, including risk factors, see "Item 1A. Risk Factors." in the Company's Annual Report on Form 10-K for the year ended December 31, 2021. For further discussion on litigation and regulatory challenges affecting the MVP project, see "Outlook" above and Part II, "Item 1. Legal Proceedings" of this Quarterly Report on Form 10-Q.

Potential Future Impairments. The accounting estimates related to impairments are susceptible to change, including estimating fair value which requires considerable judgment. For goodwill, management’s estimate of a reporting unit’s future financial results is sensitive to changes in assumptions, such as changes in stock prices, weighted-average cost of capital, terminal growth rates and industry multiples. Similarly, cash flow estimates utilized for purposes of evaluating long-lived assets and equity method investment (such as in the MVP Joint Venture) require the Company to make projections and assumptions for many years into the future for pricing, demand, competition, operating costs, commencement of operations, resolution of relevant legal and regulatory matters, and other factors. The Company evaluates long-lived assets and equity method investments for impairment when events or changes in circumstances indicate, in management’s judgment, that the carrying value of such assets may not be recoverable (meaning, in the case of its equity method investment, that such investment has suffered other-than-

Table of Contents

temporary declines in value under ASC 323). The Company believes the estimates and assumptions used in estimating its reporting units’, its long-lived assets' and its equity investment's fair values are reasonable and appropriate as of March 31, 2022; however, assumptions and estimates are inherently subject to significant business, economic, competitive, regulatory, judicial and other risks that could materially affect the calculated fair values and the resulting conclusions regarding impairments, which could materially affect the Company’s results of operations and financial position. Additionally, actual results could differ from these estimates and assumptions may not be realized. The Company also continues to evaluate and monitor the ongoing legal and regulatory matters affecting the MVP and MVP Southgate projects, as further described in Part II, “Item 1. Legal Proceedings” of this Quarterly Report on Form 10-Q. Further adverse or delayed developments with respect to such matters or other adverse developments could require that the Company modify assumptions reflected in the probability-weighted scenarios of discounted future net cash flows (including with respect to the probability of success) utilized to estimate the fair value of its equity investment in the MVP Joint Venture, which could result in an other-than-temporary decline in value, resulting in an incremental impairment of that investment. See “Reviews of our goodwill, intangible and other long-lived assets and equity method investment in the MVP Joint Venture have resulted in significant impairment charges, and reviews of our goodwill, intangible and other long-lived assets and equity method investment in the MVP Joint Venture could result in future significant impairment charges.” included in “Item 1A. Risk Factors" in the Company's Annual Report on Form 10-K for the year ended December 31, 2021 and the Company's discussion of "Critical Accounting Estimates" included in "Item 7. Management's Discussion and Analysis of Financial Condition and Results of Operations" in the Company's Annual Report on Form 10-K for the year ended December 31, 2021.

As of the filing of this Quarterly Report on Form 10-Q, the Company cannot predict the likelihood or magnitude of any future impairment.

For a discussion of capital expenditures, see "Capital Requirements" below.

Capital Resources and Liquidity

The Company's liquidity requirements are to finance its operations, its capital expenditures, potential acquisitions and other strategic transactions and capital contributions to joint ventures, including the MVP Joint Venture, to pay cash dividends and to satisfy any indebtedness obligations. The Company's ability to meet these liquidity requirements depends on the Company's cash flow from operations, the continued ability of the Company to borrow under its credit facilities and the Company's ability to raise capital in banking and capital markets. We believe that our cash on hand and future cash generated from operations, together with available borrowing capacity under our subsidiaries' credit facilities and our access to banking and capital markets, will provide adequate resources to fund our short-term and long-term capital, operating and financing needs. However, cash flow and capital raising activities may be affected by prevailing economic conditions in the natural gas industry, including, in the case of capital raising activities, volatility related to the ongoing conflict in Ukraine, and other financial and business factors (including those market forces discussed in “Our business is subject to climate change-related transitional risks (including evolving climate-focused regulation and climate change-driven trends emphasizing financing non-fossil fuel businesses and prompting pursuit of emissions reductions, lower-carbon technologies and alternative forms of energy) and physical risks that could significantly increase our operating expenses and capital costs, adversely affect our customers’ development plans, and reduce demand for our products and services." included in "Item 1A. Risk Factors" in the Company's Annual Report on Form 10-K for the year ended December 31, 2021), some of which are beyond the Company's control. The Company's available sources of liquidity include cash from operations, cash on hand, borrowings under its subsidiaries' revolving credit facilities, issuances of additional debt and issuances of additional equity securities. As of March 31, 2022, pursuant to the terms of the Amended EQM Credit Facility, EQM would have been able to borrow approximately $1.1 billion under the Amended EQM Credit Facility. The amount the Company is able to borrow under the Amended EQM Credit Facility is bounded by a maximum consolidated leverage ratio. See Note 6 and Note 10 to the consolidated financial statements for further information regarding the Amended EQM Credit Facility.

See “Security Ratings” below for a discussion of EQM’s credit ratings during 2022. Based on EQM's credit rating levels, EQM has delivered credit support to the MVP Joint Venture in the form of letters of credit, which, in the case of the MVP project, is in the amount of approximately $219.7 million and is, in the case of the MVP Southgate project, $14.2 million, in each case as of March 31, 2022 and which are subject to adjustment based on the applicable construction budget. In connection with delivering such letters of credit as replacement performance assurances, EQM's performance guarantees associated with the MVP and MVP Southgate projects were terminated. Additionally, pursuant to the EQT Global GGA, if EQM does not maintain minimum credit ratings from two of three credit rating agencies of at least Ba3 with respect to Moody's and BB- with respect to S&P and Fitch, EQM will be obligated to provide additional credit support in an amount equal to approximately $196 million to EQT in support of the potential payment obligation related to the EQT Cash Option (the Cash Option Letter of Credit). See "A further downgrade of EQM’s credit ratings, including in connection with the MVP project or customer credit ratings changes, which are determined by independent third parties, could impact our liquidity, access to capital, and costs of doing

Table of Contents

business." included in "Item 1A. Risk Factors" in the Company’s Annual Report on Form 10-K for the year ended December 31, 2021.

Operating Activities

Net cash flows provided by operating activities were $185.9 million for the three months ended March 31, 2022 compared to $229.6 million for the three months ended March 31, 2021. The decrease was primarily driven by the timing of working capital receipts and payments.

Investing Activities

Net cash flows used in investing activities were $142.5 million for the three months ended March 31, 2022 compared to $70.7 million for the three months ended March 31, 2021. Investing activities increased by approximately $71.8 million for the three months ended March 31, 2022 as compared to the three months ended March 31, 2021, primarily due to an increase in capital contributions to the MVP Joint Venture related to work completed in late 2021 and ongoing right-of-way maintenance, as well as an increase in capital expenditure spending on various wellhead gathering and water projects. See “Capital Requirements” below for a discussion of forecasted 2022 capital expenditures and capital contributions to the MVP Joint Venture.

Financing Activities

Net cash flows used in financing activities were $136.5 million for the three months ended March 31, 2022 compared to $135.0 million for the three months ended March 31, 2021. For the three months ended March 31, 2022, the primary uses of financing cash flows were net repayments on borrowings under the revolving credit facilities, and the payment of dividends to shareholders, while the primary source of financing cash flows was borrowings under the revolving credit facilities. For the three months ended March 31, 2021, the primary uses of financing cash flows were the payment for retirement of the EQM Term Loans and termination of the Amended 2019 EQM Term Loan Agreement, the Company's purchase of an aggregate principal amount of $500 million of EQM's 2023 Notes pursuant to the Tender Offers and the payment of dividends to shareholders, while the primary source of financing cash flows were the issuance of the 2021 Senior Notes and borrowings under the Former Eureka Credit Facility.

Capital Requirements

The gathering, transmission and storage and water services businesses are capital intensive, requiring significant investment to develop new facilities and to maintain and upgrade existing operations.

Capital expenditures in 2022 are expected to be approximately $390 million to $440 million (including approximately $20 million attributable to the noncontrolling interest in Eureka Midstream). The Company expects to make capital contributions to the MVP Joint Venture in 2022 of approximately $175 million to $225 million for purposes of the MVP project primarily related to work completed in late 2021 and ongoing work required for right-of-way maintenance and approximately $5 million related to the MVP Southgate project. Capital contributions payable to the MVP Joint Venture are accrued upon the issuance of a capital call by the MVP Joint Venture. The Company's short-term and long-term capital investments may vary significantly from period to period based on the available investment opportunities, the timing of the construction of the MVP, MVP Southgate and other projects, and maintenance needs. The Company expects to fund short-term and long-term capital expenditures and capital contributions primarily through cash on hand, cash generated from operations, available borrowings under its subsidiaries' credit facilities and its access to banking and capital markets.

See Note 10 for a discussion of the reduction of commitments under the Amended EQM Credit Facility pursuant to the Third Amendment.

Credit Facility Borrowings

See Note 6 and Note 10 to the consolidated financial statements for discussion of the Amended EQM Credit Facility, and the 2021 Eureka Credit Facility.

Table of Contents

Security Ratings

The table below sets forth the credit ratings for EQM's debt instruments at March 31, 2022.

EQM

Senior Notes

Rating Service

Rating

Outlook

Moody's

Ba3

Negative

S&P

BB-

Stable

Fitch

Negative

There were no changes to EQM's credit ratings during the three months ended March 31, 2022. EQM's credit ratings are subject to revision or withdrawal at any time by the assigning rating organization, and each rating should be evaluated independently of any other rating. The Company cannot ensure that a rating will remain in effect for any given period of time or that a rating will not be lowered or withdrawn entirely by a credit rating agency if, in its judgment, circumstances so warrant. If any credit rating agency downgrades or withdraws EQM's ratings, including for reasons relating to the MVP project (such as delays in the targeted full in-service date of the MVP project or increases in such project’s targeted costs), EQM’s leverage or credit ratings of the Company's customers, the Company's access to the capital markets could become more challenging, borrowing costs will likely increase, the Company may be required to provide additional credit assurances (the amount of which may be substantial), including the Cash Option Letter of Credit, in support of commercial agreements such as joint venture agreements, and the potential pool of investors and funding sources may decrease. In order to be considered investment grade, a company must be rated Baa3 or higher by Moody's, BBB- or higher by S&P, or BBB- or higher by Fitch. All of EQM's credit ratings are considered non-investment grade.

Commitments and Contingencies

In the ordinary course of business, various legal and regulatory claims and proceedings are pending or threatened against the Company and its subsidiaries. While the amounts claimed may be substantial, the Company is unable to predict with certainty the ultimate outcome of such claims and proceedings. The Company accrues legal and other direct costs related to loss contingencies when incurred. The Company establishes reserves whenever it believes it to be appropriate for pending matters. Furthermore, after consultation with counsel and considering available insurance, the Company believes that the ultimate outcome of any matter currently pending against it or any of its consolidated subsidiaries will not materially affect its business, financial condition, results of operations, liquidity or ability to pay dividends to its shareholders.

See "The regulatory approval process for the construction of new midstream assets is very challenging, has significantly increased costs and delayed targeted in-service dates, and decisions by regulatory and judicial authorities in pending or potential proceedings are likely to impact our or the MVP Joint Venture's ability to obtain or maintain in effect all approvals and authorizations necessary to complete certain projects on the targeted time frame or at all or our ability to achieve the expected investment returns on the projects." under "Item 1A. Risk Factors" in the Company's Annual Report on Form 10-K for the year ended December 31, 2021 and Part II, "Item 1. Legal Proceedings" of this Quarterly Report on Form 10-Q for discussion of certain litigation and regulatory proceedings, including related to the MVP and MVP Southgate projects.

See Note 16 to the annual consolidated financial statements included in the Company's Annual Report on Form 10-K for the year ended December 31, 2021 for further discussion of the Company's commitments and contingencies.

Dividends

On April 26, 2022, the Board declared cash dividends for the first quarter of 2022 of $0.15 per common share and $0.4873 per Equitrans Midstream Preferred Share to shareholders of record at the close of business on May 4, 2022.

Critical Accounting Estimates

The Company's critical accounting policies are described in "Item 7. Management's Discussion and Analysis of Financial Condition and Results of Operations" contained in the Company's Annual Report on Form 10-K for the year ended December 31, 2021. Any new accounting policies or updates to existing accounting policies as a result of new accounting pronouncements have been included in the notes to the Company's consolidated financial statements in Part I, "Item 1. Financial Statements" of this Quarterly Report on Form 10-Q. The Company's critical accounting policies are considered critical due to the significant judgments and estimates used in the preparation of the Company's consolidated financial

Table of Contents

statements and the material impact on the results of operations or financial condition. Actual results could differ from those judgments and estimates.

Item 3. Quantitative and Qualitative Disclosures About Market Risk

Interest Rate Risk. Changes in interest rates affect the amount of interest the Company earns on cash, cash equivalents and short-term investments and the interest rates EQM and Eureka pay on borrowings under their respective revolving credit facilities. The Amended EQM Credit Facility and the 2021 Eureka Credit Facility provide for variable interest rates and thus expose the Company, through EQM and Eureka, to fluctuations in market interest rates. In addition, EQM's interest rates under the Amended EQM Credit Facility are impacted by changes in EQM's credit ratings (which may be caused by factors outside of EQM's control). Eureka's interest rates under the 2021 Eureka Credit Facility are impacted by changes in Eureka's Consolidated Leverage Ratio (as defined in the 2021 Eureka Credit Facility) which may fluctuate based on Eureka Midstream's liquidity needs or operating results. Accordingly, changes in interest rates may impact the Company's results of operations and liquidity. Further, changes in interest rates may affect the dividend payable on Equitrans Midstream Preferred Shares after March 31, 2024, which could affect the amount of cash the Company has available to make quarterly cash dividends to its shareholders. EQM's senior notes are fixed rate and thus do not expose the Company to fluctuations in market interest rates. Changes in interest rates do affect the fair value of EQM's fixed rate debt. See Notes 6 and 7 to the consolidated financial statements for discussion of borrowings and for discussion of fair value measurements, respectively. EQM and Eureka may from time to time hedge the interest on portions of borrowings under the revolving credit facilities, as applicable, in order to manage risks associated with floating interest rates (however, there may be no assurance that such hedges will fully mitigate interest rate risk).

Credit Risk. The Company is exposed to credit risk, which is the risk that it may incur a loss if a counterparty fails to perform under a contract. The Company actively manages its exposure to credit risk associated with customers through credit analysis, credit approval and monitoring procedures. For certain transactions, the Company requests letters of credit, cash collateral, prepayments or guarantees as forms of credit support. Equitrans, L.P.'s FERC tariffs require tariff customers that do not meet specified credit standards to provide three months of credit support; however, the Company is exposed to credit risk beyond this three-month period when its tariffs do not require its customers to provide additional credit support. For some of the Company's long-term contracts associated with system expansions, it has entered into negotiated credit agreements that provide for other credit support if certain credit standards are not met. The Company has historically experienced only minimal credit losses in connection with its receivables.

The Company is exposed to the credit risk of its customers, including its largest customer, EQT, including as a result of changes in customer credit ratings, liquidity and access to capital markets. At March 31, 2022, EQT's public senior debt had investment grade credit ratings from Standard & Poor's Global Ratings and Fitch Ratings and a non-investment grade credit rating from Moody's Investor Services. In addition, EQT has guaranteed the payment obligations of certain of its subsidiaries, up to a maximum amount of $115 million, $131 million and $30 million related to gathering, transmission and water services, respectively, across all applicable contracts, for the benefit of the subsidiaries of the Company providing such services. See Note 15 to the annual consolidated financial statements included in the Company's Annual Report on Form 10-K for the year ended December 31, 2021 for further discussion of the Company's exposure to credit risk.

Commodity Prices. The Company's business is dependent on continued natural gas production and the availability and development of reserves in its areas of operation. Prices for natural gas and NGLs, including regional basis differentials, have previously adversely affected, and may in the future adversely affect, timing of development of additional reserves and production that is accessible by the Company’s pipeline and storage assets, which also negatively affects the Company’s water services business, and the creditworthiness of the Company’s customers.

Increases in natural gas prices do not necessarily result in corresponding increases to the production forecasts of the Company's customers and, as of the date of this Quarterly Report on Form 10-Q, the Company's largest customers have continued to maintain their production forecasts without significant increases. Even at commercially attractive natural gas prices, the Company's customers may still maintain flat or modest increases to production forecasts based on various factors, which could include regional takeaway capacity limitations, access to capital, investor expectations regarding free cash flow, a desire to reduce or refinance leverage or other factors. Additionally, prices may decline based on numerous factors, including levels of associated gas. See also “Decreases in production of natural gas in our areas of operation, whether as a result of producer corporate capital allocation strategies, lower regional natural gas prices, regional takeaway constraints, and/or other factors, have adversely affected, and in the future could adversely affect, our business and operating results and reduce our cash available to pay cash dividends to our shareholders.” and "The lack of diversification of our assets and geographic locations could adversely affect us." under "Item 1A. Risk Factors" in the Company's Annual Report on Form 10-K for the year ended December 31, 2021.

Table of Contents

Lower natural gas prices, particularly in the Appalachian region, have in the past caused, and may in the future cause, certain producers, including customers of the Company, to determine to reduce or hold generally steady their rig count (and thereby delay or not increase production), delay turning wells in line, temporarily shut in portions of their production or otherwise take actions to slow production growth and/or reduce production, which when effected by the Company's producer customers reduces the demand for, and usage of, the Company’s services. For instance, temporary production curtailments have previously resulted in a decrease in the Company's volumetric-based fee revenues. An extended period of low natural gas prices and/or instability in natural gas prices in future periods, especially in the Appalachian region, or other factors, could cause EQT or other producers to curtail production in the future, which could have a significant negative effect on the demand for the Company's services and therefore its results of operations. Additionally, lower natural gas prices (including regionally), corporate capital allocation strategies or regional takeaway constraints, could cause producers to determine in the future that drilling activities in areas outside of the Company's current areas of operation are strategically more attractive to them.

Many of the Company’s customers, including EQT, have entered into long-term firm reservation gathering, transmission and water contracts or contracts with MVCs on the Company's systems and approximately 71% of the Company's operating revenues for the three months ended March 31, 2022 was generated by firm reservation fees. As a result, the Company believes that the effect of temporary declines in volumes of gas gathered, transported or stored on its systems may be mitigated because firm reservation fee revenues are paid regardless of volumes supplied to the system by customers (although significant declines in gas production in the Company's areas of operations would adversely affect the Company's results of operations, financial condition and liquidity as approximately 29% of the Company’s operating revenues for the three months ended March 31, 2022 was generated by volumetric-based fee revenues). See "Our exposure to direct commodity price risk may increase in the future." under "Item 1A. Risk Factors" in the Company's Annual Report on Form 10-K for the year ended December 31, 2021.

Price declines and sustained periods of low natural gas and NGL prices could have an adverse effect on the creditworthiness of the Company's customers and related ability to pay firm reservation fees under long-term contracts and/or affect, as discussed above, activity levels and, accordingly, volumetric-based fees, which could affect the Company’s results of operations, liquidity or financial position. Credit risk and related management is further discussed above under “Credit Risk” in Part I, “Item 3. Quantitative and Qualitative Disclosures About Market Risk” of this Quarterly Report on Form 10-Q.

Unless the Company is successful in attracting and retaining new customers, the Company's ability to maintain or increase the capacity subscribed and volumes transported, gathered or provided on its systems will be dependent on receiving consistent or increasing commitments and production from its existing customers, which may be impacted by commodity prices, including regional commodity prices and/or other factors, including corporate capital allocation strategies. While EQT has dedicated a substantial portion of its core acreage to the Company and has entered into long-term firm gathering and transmission contracts and contracts with MVCs on certain of the Company's systems, EQT may determine in the future that drilling or continuing to produce gas from existing wells in the Company's areas of operations is not economical above the amount to fulfill its required MVCs or otherwise strategically determine to curtail volumes on the Company's systems. Other than with respect to its MVCs and other firm commitments under existing contracts, EQT is under no contractual obligation to continue to develop its acreage dedicated to the Company. See also "Outlook" for a discussion of the EQT Global GGA and the 2021 Water Services Agreement.

The fair value of the Company’s derivative instruments is, in part, determined by estimates of the NYMEX Henry Hub natural gas forward price curve. A hypothetical 10% increase in NYMEX Henry Hub natural gas futures prices would increase the valuation of the Company’s derivative instruments by approximately $5.5 million, while a hypothetical 10% decrease in NYMEX Henry Hub natural gas futures prices would decrease the valuation of the Company’s derivative instruments by approximately $6.2 million. This fair value change assumes volatility based on prevailing market parameters at March 31, 2022. See "Outlook" and Note 7 for a discussion of the Henry Hub cash bonus payment provision.

For further discussion of commodity prices and related risks, see "Our exposure to direct commodity price risk may increase in the future." and "Decreases in production of natural gas in our areas of operation, whether as a result of producer corporate capital allocation strategies, lower regional natural gas prices, regional takeaway constraints, and/or other factors have adversely affected, and in the future could adversely affect, our business and operating results and reduce our cash available to pay cash dividends to our shareholders" and "The lack of diversification of our assets and geographic locations could adversely affect us.", each under "Item 1A. Risk Factors" in the Company's Annual Report on Form 10-K for the year ended December 31, 2021.

Other Market Risks. The Amended EQM Credit Facility is underwritten by a syndicate of 21 financial institutions until the Earlier Maturity Date, and a syndicate of 14 financial institutions from the Earlier Maturity Date through the Later Maturity Date. The 2021 Eureka Credit Facility is underwritten by a syndicate of 16 financial institutions. Each financial institution is obligated to fund its pro rata portion of any borrowings by EQM or Eureka, as applicable. In each case, no one lender of the financial institutions in the syndicate holds more than 10% of such facility. EQM's and Eureka's respective large syndicate

Table of Contents

groups and relatively low percentage of participation by each lender is expected to limit the Company's and Eureka's respective exposure to disruption or consolidation in the banking industry. See Note 10 for a discussion of the Third Amendment to the EQM Credit Facility.

Table of Contents

Item 4. Controls and Procedures

Evaluation of Disclosure Controls and Procedures. Under the supervision and with the participation of management, including the Company’s Principal Executive Officer and Principal Financial Officer, an evaluation of the Company’s disclosure controls and procedures (as defined in Rule 13a-15(e) under the Exchange Act) was conducted as of the end of the period covered by this report. Based on that evaluation, the Principal Executive Officer and Principal Financial Officer concluded that the Company’s disclosure controls and procedures were effective as of the end of the period covered by this report.

Changes in Internal Control over Financial Reporting. There were no changes in the Company's internal control over financial reporting (as such term is defined in Rule 13a-15(f) under the Exchange Act) that occurred during the first quarter of 2022 that have materially affected, or are reasonably likely to materially affect, the Company's internal control over financial reporting.

Table of Contents

PART II. OTHER INFORMATION

Item 1. Legal Proceedings

Environmental Proceedings

Pratt Storage Field. On October 31, 2018, a gas explosion occurred in Morgan Township, Greene County, Pennsylvania (the Incident). Following the explosion, the Pennsylvania Department of Environmental Protection (the PADEP), the Pennsylvania Public Utilities Commission and the PHMSA began investigating the Incident. The Company is awaiting further direction or inquiry from the PADEP. If a penalty is imposed it could result in monetary sanctions in excess of $300,000. However, the Company does not believe that the penalty, if imposed, will have a material impact on the financial condition, results of operations or liquidity of the Company. Additionally, the Company is responding to civil and criminal investigations related to the Incident.

EPA Finding of Violation. On October 28, 2021, the Company submitted its annual report to the EPA pursuant to New Source Performance Standards subpart OOOOa (Subpart OOOOa) of the Clean Air Act that included deviations from Subpart OOOOa requirements related to certain high bleed controllers that were discovered in October 2020. On March 1, 2022, EPA issued a Finding of Violation for alleged violations of Subpart OOOOa in response to the deviations included in the annual report. Although all high bleed controllers identified in the Finding of Violation have been converted to compressed air or low bleed devices that comply with Subpart OOOOa, the Company cannot predict what criminal and/or civil enforcement action, if any, EPA may pursue against the Company. If a penalty is imposed, it could result in monetary sanctions in excess of $300,000. However, the Company does not believe that the penalty, if imposed, will have a material impact on the financial condition, results of operations or liquidity of the Company.

MVP Matters

The MVP Joint Venture is currently defending certain agency actions and judicial challenges to the MVP, any of which could affect the ability to complete or operate the project, including the following:

•Sierra Club, et al. Petitioners v. State Water Control Board, et al. Respondents and Mountain Valley Pipeline, Intervenor, Docket No. 21-2425, Fourth Circuit Court of Appeals (Fourth Circuit). On December 20, 2021, the Virginia Department of Environmental Quality (VADEQ) certified that the MVP project would satisfy Virginia’s water quality standards based on its comprehensive nine-month review of the MVP Joint Venture’s Joint Permit Application (VA 401 Permit). On December 22, 2021, Petitioners filed their petition challenging the VADEQ’s approval of the VA 401 Permit with the Fourth Circuit. On December 22, 2021, the Petitioners filed a request for an administrative stay with the VADEQ which was denied on January 4, 2022. On January 4, 2022, the Petitioners filed a petition with the Fourth Circuit seeking a judicial stay of the VA 401 Permit pending a decision on the merits. On February 11, 2022, Petitioners withdrew the stay petition. Briefing is scheduled to be completed by June 2022 and oral argument to occur in the fall of 2022. If the challenge were successful on its merits, it could result in the MVP Joint Venture's VA 401 Permit being delayed or vacated and/or additional legal proceedings, the outcome of which the Company cannot predict, and cause a delay or further delay in the targeted full in-service date for the MVP project (and consequent impacts related to such delay), or otherwise adverse effects.

•Sierra Club, et al. Petitioners v. West Virginia Department of Environmental Protection, et al. Respondents and Mountain Valley Pipeline, Intervenor, Docket No. 22-1008, Fourth Circuit. On December 30, 2021, the West Virginia Department of Environmental Protection (WVDEP) certified that the MVP project would satisfy West Virginia’s water quality standards based on its comprehensive nine-month review of the MVP Joint Venture’s Joint Permit Application (WV 401 Permit). On January 3, 2022, Petitioners filed their petition challenging the WVDEP’s approval of the WV 401 Permit with the Fourth Circuit. On January 4, 2022, the Petitioners filed a request for an administrative stay with the WVDEP which was denied on January 11, 2022. On January 11, 2022, Petitioners filed a petition with the Fourth Circuit seeking a judicial stay of the WV 401 Permit pending a decision on the merits. The stay petition was denied by the Fourth Circuit on February 8, 2022. Briefing is scheduled to be completed by June 2022 and oral argument to occur in the fall of 2022. If the challenge were successful on its merits, it could result in the MVP Joint

Table of Contents

Venture's WV 401 Permit being delayed or vacated and/or additional legal proceedings, the outcome of which the Company cannot predict, and cause a delay or further delay in the targeted full in-service date for the MVP project (and consequent impacts related to such delay), or otherwise adverse effects.

•Jefferson National Forest Crossing and Associated Authorizations. In a different Fourth Circuit appeal, Sierra Club, et al. v. U.S. Forest Service, et al., consolidated under Case No. 17-2399, Fourth Circuit, filed in December 2017, the Sierra Club challenged a Bureau of Land Management (BLM) decision to grant a right-of-way to the MVP Joint Venture and a U.S. Forest Service (USFS) decision to amend its management plan to accommodate the MVP, both of which affect the MVP's approximate 3.5-mile segment in the Jefferson National Forest (JNF) in Virginia. On July 27, 2018, agreeing in part with the Sierra Club, the Fourth Circuit vacated the BLM and USFS decisions, finding fault with the BLM's analysis of the practicality of alternate routes and the USFS' analysis of erosion and sedimentation effects. The USFS published a draft Supplemental Environmental Impact Statement (SEIS) to the 2017 FERC Final Environmental Impact Statement for MVP in the Federal Register on September 25, 2020 with a public comment period that closed on November 9, 2020. On December 11, 2020, the USFS published a Final SEIS that addressed the issues raised in the prior proceedings and evaluated the most recent sedimentation analysis submitted to the agency consistent with the findings presented in MVP’s Biological Opinion and Incidental Take Statement issued by the Department of the Interior's Fish and Wildlife Service (FWS) on September 4, 2020. See Appalachian Voices, et al. v. U.S. Dep’t of Interior below for additional information. On January 11, 2021, the MVP Joint Venture received final approval of the Record of Decision from the USFS and, on January 15, 2021, the BLM issued the required right-of-way permit for the MVP’s 3.5-mile segment in the JNF in Virginia (the JNF Right-of-Way). On January 11, 2021, Sierra Club, et al. filed a petition with the Fourth Circuit to reverse the USFS approval of the Record of Decision and, on January 15, 2021, filed a petition with the Fourth Circuit challenging BLM’s grant of the JNF Right-of-Way. See Wild Virginia, et al. v. United States Forest Service, et al., No. 21-1039(L). The Fourth Circuit consolidated the challenges to the Record of Decision and the JNF Right-of-Way and briefing was completed. Oral argument occurred on October 29, 2021. On January 25, 2022, the Fourth Circuit, agreeing in part with the petitioners, vacated and remanded the Record of Decision and the JNF Right-of-Way, finding fault with (i) the USFS’ and BLM’s consideration of certain data from the U.S. Geological Survey and (ii) the USFS’ and BLM’s authorization of the use of conventional bores for stream crossings within the JNF based on a variance issued by the FERC, and, as a result of such issues, (iii) the USFS’ amendments in connection with the Record of Decision to the Jefferson Forest plan. On March 11, 2022, the MVP Joint Venture requested that the Fourth Circuit review the January 25, 2022 decision en banc, which rehearing was denied by the Fourth Circuit on March 25, 2022. The vacatur of the Record of Decision and the JNF Right-of-Way caused a delay in the targeted full in-service date for the MVP project (and consequent impacts relating to such delay). The Company cannot predict whether and when any new authorizations will be received from the USFS and BLM and, if received, the result of any challenge to such authorizations.

On August 3, 2018, citing the court's vacatur and remand in Sierra Club, et al. v. U.S. Forest Service, et al., consolidated under Case No. 17-2399, the FERC issued a stop work order for the entire pipeline pending the agency actions on remand. The FERC modified its stop work order on August 29, 2018 to allow work to continue on all but approximately 25 miles of the project (the Exclusion Zone). On October 10, 2018, the Fourth Circuit granted a petition for rehearing filed by the MVP Joint Venture for the limited purpose of clarifying that the July 27, 2018 order did not vacate the portion of the BLM's Record of Decision authorizing a right-of-way and temporary use permit for the MVP to cross the Weston and Gauley Bridge Turnpike Trail in Braxton County, West Virginia. On October 15, 2018, the MVP Joint Venture filed with the FERC a request to further modify the August 3, 2018 stop work order to allow the MVP Joint Venture to complete the bore and install the pipeline under the Weston and Gauley Bridge Turnpike Trail. On October 24, 2018, the FERC granted the MVP Joint Venture's request to further modify the stop work order and authorize construction. Additionally, on October 9, 2020, the FERC authorized construction to resume project-wide (as it had been stopped by the FERC on October 15, 2019 in relation to a separate matter discussed below), other than with respect to the Exclusion Zone, which requires additional authorization. On December 17, 2020, the FERC again modified the stop work order and authorized construction to resume in 17 miles of the Exclusion Zone. The Company cannot guarantee whether or when the FERC will act in respect of any or all of the remaining portions of the Exclusion Zone. The FERC's October 9, 2020 and December 17, 2020 actions are the subject of challenges filed by the Sierra Club in Sierra Club, et al. v. FERC, Case No. 20-1512 (consolidated with No. 21-1040), D.C. Circuit Court of Appeals on December 22, 2020 and January 25, 2021, respectively (a stay request filed by the Sierra Club on January 29, 2021 was denied by the Court of Appeals for the D.C. Circuit (DC Circuit) on February 19, 2021). Briefing in Sierra Club, et al. v. FERC, Case No. 20-1512 (consolidated with No. 21-1040), D.C. Circuit Court of Appeals was completed in January 2022 and oral argument occurred on April 7, 2022. If any of the challenges to the FERC's October 9, 2020 and December 17, 2020 orders are successful, it could result in the FERC's orders being vacated and/or additional agency proceedings (the outcome of which the Company cannot predict) and cause a delay or further

Table of Contents

delay in the targeted full in-service date for the MVP project (and consequent impacts relating to such delay), or otherwise adverse effects.

•Challenges to FERC Certificate, Court of Appeals for DC Circuit. Multiple parties have sought judicial review of the FERC's order issuing a certificate of public convenience and necessity to the MVP Joint Venture and/or the exercise by the MVP Joint Venture of eminent domain authority. On February 19, 2019, the DC Circuit issued an order rejecting multiple consolidated petitions seeking direct review of the FERC order under the NGA and certain challenges to the exercise by the MVP Joint Venture of eminent domain authority in Appalachian Voices, et al. v. FERC, et al., consolidated under Case No. 17-1271. No petitions for rehearing or petitions for rehearing en banc were filed by the April 5, 2019 deadline. The mandate was issued on April 17, 2019. Another group of parties filed a complaint in the U.S. District Court for the District of Columbia asserting that the FERC's order issuing certificates is unlawful on constitutional and other grounds in Bold Alliance, et al. v. FERC, et al., Case No. 17-1822. The district court plaintiffs sought declaratory relief as well as an injunction preventing the MVP Joint Venture from developing its project or exercising eminent domain authority. In December 2017 and January 2018, the FERC and the MVP Joint Venture, respectively, moved to dismiss the petitions for lack of subject matter jurisdiction. The court granted the motion and dismissed plaintiffs' complaint on September 28, 2018. On October 26, 2018, plaintiffs appealed the decision in Case No. 17-1822 to the DC Circuit in Bold Alliance, et al. v. FERC, et al., Case No. 18-5322. On December 3, 2018, the FERC, as appellee, filed a joint motion with the appellants to hold Case No. 18-5322 in abeyance pending completion of the appeals of the final agency orders related to the MVP certificate in consolidated Case No. 17-1271 and Atlantic Coast Pipeline’s (ACP) certificate. The MVP Joint Venture filed a motion to dismiss the case as to some of the plaintiffs. On February 15, 2019, the DC Circuit entered an order holding this appeal in abeyance pending rulings on the appeals from the ACP and MVP FERC proceedings. Although the members of the ACP project announced the cancellation of that project on July 5, 2020, ACP's proceeding remains pending. Case No. 18-5322 remains in abeyance. Similarly, another group of parties filed a complaint in the U.S. District Court for the District of Columbia in Bohon et al. v. FERC et al., Case No. 20-00006, asserting that the delegation of authority to FERC under the NGA violates the nondelegation doctrine and separation-of-powers principle of the U.S. Constitution. The MVP Joint Venture and the FERC filed motions to dismiss which were granted by the court. On July 6, 2020, the landowners filed a notice of appeal to the DC Circuit in Case No. 20-5203. On November 30, 2020, appellants asked the DC Circuit to overturn the decision of the lower court. Oral argument before the DC Circuit was scheduled for March 29, 2021, but the court cancelled and held oral argument in abeyance and directed the parties to file motions to govern future proceedings following a decision by the U.S. Supreme Court in PennEast Pipeline Co. v. New Jersey, Case No. 19-1039, which decision was published on June 29, 2021. Briefing in Bohon et al. v. FERC et al., Case No. 20-00006 on the significance of the PennEast Pipeline Co. opinion was completed on July 29, 2021. The DC Circuit issued an order on September 15, 2021 denying appellants' motion for summary reversal of the decision of the lower court and supplemental briefing was completed as of October 6, 2021. Oral argument occurred on December 15, 2021 and the parties are awaiting a decision. Due to the uncertainty regarding the timing of permitting and the outcome of legal challenges facing the MVP project, on August 25, 2020, the MVP Joint Venture filed a request with the FERC for and, on October 9, 2020, the FERC granted, an extension of time to complete the MVP project for an additional two years through October 13, 2022. On December 22, 2020, a challenge to the FERC’s action to grant an extension of time to complete the MVP project was filed in the DC Circuit in Sierra Club, et al. v. FERC, Case No. 20-1512 (consolidated with No. 21-1040, DC Circuit). On January 29, 2021, Sierra Club requested a stay of the FERC’s action to grant the MVP Joint Venture an extension of time to complete the MVP project from the DC Circuit, which stay request was denied by the DC Circuit on February 19, 2021. Briefing in Sierra Club, et al. v. FERC, Case No. 20-1512 (consolidated with No. 21-1040, D.C. Circuit), was completed in January 2022 and oral argument occurred on April 7, 2022. If any of these challenges were successful, it could result in the MVP Joint Venture's certificate of public convenience and necessity being vacated and/or additional proceedings before the FERC, the outcome of which the Company cannot predict, and cause a delay or further delay in the targeted full in-service date for the MVP project (and consequent impacts related to such delay), or otherwise adverse effects.

•Appalachian Voices, et al. v. U.S. Dep’t of Interior, et al., Fourth Circuit Court of Appeals, Case No. 20-2159. In August 2019, Wild Virginia and certain other petitioners filed a petition in the Fourth Circuit in Wild Virginia et al. v. United States Department of the Interior; Case No. 19-1866, to challenge the MVP Joint Venture’s Biological Opinion and Incidental Take Statement issued by FWS which was approved in November 2017 (the Original BiOp). On October 11, 2019, the Fourth Circuit issued an order approving the petitioners’ requested stay of the Original BiOp and holding the litigation in abeyance until January 11, 2020. On October 15, 2019, the FERC issued an order requiring the MVP Joint Venture to cease all forward-construction progress (the FERC modified this order on October 9, 2020 and December 17, 2020, which the Sierra Club has appealed to the DC Circuit as discussed above under "Jefferson National Forest Crossing and Associated Authorizations"). On September 4, 2020, FWS issued the MVP Joint Venture a new Biological Opinion and Incidental Take Statement (the New BiOp) for the MVP project and the Fourth Circuit

Table of Contents

subsequently dismissed the litigation regarding the Original BiOp. On October 27, 2020, Appalachian Voices et al. filed a petition with the Fourth Circuit challenging the New BiOp and filed a request for an administrative stay of the New BiOp with FWS, which FWS subsequently denied. On November 2, 2020, the petitioners filed a motion to stay the New BiOp with the Fourth Circuit. On November 18, 2020, the Fourth Circuit issued an order denying the requested stay. The matter was fully briefed as of March 19, 2021. Oral argument occurred on October 29, 2021. On February 2, 2022, the Fourth Circuit vacated and remanded the New BiOp holding, in part, that the FWS did not adequately analyze the environmental context for species at issue. On March 11, 2022, the MVP Joint Venture requested that the Fourth Circuit review the February 2, 2022 decision en banc, which rehearing was denied by the Fourth Circuit on April 1, 2022. The vacatur of the New BiOp caused a delay in the targeted full in-service date for the MVP project (and consequent impacts relating to such delay). The Company cannot predict whether and when a new BiOp will be received from the FWS and, if received, the result of any challenge to such BiOp.

MVP Southgate Matters

The MVP Joint Venture is currently challenging or defending certain agency actions and judicial challenges to the MVP Southgate project that must be resolved in connection with the project, in addition to working to address matters affecting the MVP, including the following:

•Sierra Club et al. v. FERC; Case No. 20-1427, DC Circuit. On June 18, 2020, the FERC issued an order granting a certificate of public convenience and necessity for the MVP Southgate project. However, the FERC, while authorizing the project, directed the Office of Energy Projects not to issue a notice to proceed with construction until necessary federal permits are received for the MVP project and the Director of the Office of Energy Projects lifts the stop-work order and authorizes the MVP Joint Venture to continue constructing the MVP project. Certain opposition parties subsequently requested rehearing of the certificate order. On August 20, 2020, the FERC issued an order denying requests for rehearing of that certificate order, and on September 17, 2020, the FERC issued an order addressing the arguments raised on rehearing. On October 9, 2020, Sierra Club, among other petitioners, filed an appeal of these orders with the DC Circuit. The matter has been fully briefed and oral argument was held on January 19, 2022 and the parties are awaiting a decision. If this challenge were successful, it could result in the MVP Southgate project’s certificate of public convenience and necessity being vacated and/or additional proceedings before the FERC, the outcome of which the Company cannot predict, and cause a further delay to the MVP Southgate project (and consequent impacts relating to such delay), or otherwise adverse effects.

•Mountain Valley Pipeline, LLC v. North Carolina Department of Environmental Quality, No. 20-1971, Fourth Circuit Court of Appeals. On August 11, 2020, the North Carolina Department of Environmental Quality (NCDEQ) denied the MVP Southgate project’s application for a Clean Water Act Section 401 Individual Water Quality Certification and Jordan Lake Riparian Buffer Authorization and such denial was reissued by the NCDEQ on April 29, 2021. See "MVP Southgate Project" included in "Outlook" under Part I, "Item 2. Management's Discussion and Analysis of Financial Condition and Results of Operation." for additional information. The Company is evaluating next steps, including the submission of a new application for a Clean Water Act Section 401 Individual Water Quality Certification and Jordan Lake Riparian Buffer Authorization for the MVP Southgate project, but cannot guarantee whether a new application, if submitted, will ultimately be approved or, if approved, whether conditions may be included as part of such approval or whether the application would then be further challenged.

•Mountain Valley Pipeline, LLC v. State Air Pollution Control Board et al., U.S. Court of Appeals for the Fourth Circuit. On December 3, 2021, the Virginia State Air Pollution Control Board (VAPCB) voted 5-2 to deny the air permit for the MVP Southgate project’s Lambert Compressor Station (the Lambert Air Permit). On December 31, 2021, the MVP Joint Venture filed a Petition for Review in the Fourth Circuit to review the VAPCB’s December 3, 2021 denial of the Lambert Air Permit. On March 29, 2022, the Fourth Circuit granted the MVP Joint Venture's request to withdraw its request to review the denial of the Lambert Air Permit.

Table of Contents

Item 1A. Risk Factors

There have been no material changes from the risk factors previously disclosed in the Company's Annual Report on Form 10-K for the year ended December 31, 2021.

Item 2. Unregistered Sales of Equity Securities and Use of Proceeds

Purchases of Equity Securities

The following table sets forth the Company's repurchases of equity securities registered under Section 12 of the Exchange Act that occurred during the three months ended March 31, 2022:


Period	Total number of shares purchased (a)	Average price paid per share		Total number of shares purchased as part of publicly announced plans or programs	Approximate dollar value of shares that may yet be purchased under the plans or programs
January 2022 (January 1 - January 31)	94,651	$	10.34	—	$	—
February 2022 (February 1 - February 28)	—	—		—	—
March 2022 (March 1 - March 31)	—	—		—	—
Total	94,651	$	10.34	—	$	—

(a)Reflects shares withheld by the Company to pay taxes upon vesting of restricted stock.

Table of Contents

Item 6. Exhibits

Exhibit No.

Document Description

Method of Filing

3.1

Fourth Amended and Restated Bylaws of Equitrans Midstream Corporation.

Incorporated herein by reference to Exhibit 3.1 to Form 8-K (#001-38629) filed on April 27, 2022.

10.1 #

Letter Agreement, dated as of February 1, 2022, by and between EQM Olympus Midstream, LLC and Rice Drilling D LLC.

Incorporated herein by reference to Exhibit 10.04(d) to Form 10-K (#001-38629) for the year ended December 31, 2021.

10.2 #

Letter Agreement, dated as of February 4, 2022, by and among EQM Gathering Opco, LLC, EQT Corporation, EQT Production Company, Rice Drilling B LLC, and EQT Energy, LLC.

Incorporated herein by reference to Exhibit 10.34(m) to Form 10-K (#001-38629) for the year ended December 31, 2021.

10.3 *

Equitrans Midstream Corporation 2022 Performance Share Unit Program

Incorporated herein by reference to Exhibit 10.44 to Form 10-K (#001-38629) for the year ended December 31, 2021.

10.04*

Form of Participant Award Agreement under 2022 Performance Share Unit Program

Incorporated herein by reference to Exhibit 10.45 to Form 10-K (#001-38629) for the year ended December 31, 2021.

10.05*

Form of Equitrans Midstream Corporation Restricted Stock Award Agreement (2022 Awards)

Incorporated herein by reference to Exhibit 10.46 to Form 10-K (#001-38629) for the year ended December 31, 2021.

10.06*

Equitrans Midstream Corporation Amended and Restated Executive Short-Term Incentive Plan

Incorporated herein by reference to Exhibit 10.47 to Form 10-K (#001-38629) for the year ended December 31, 2021.

10.07

Third Amendment to Third Amended and Restated Credit Agreement, dated as of April 22, 2022, by and among EQM Midstream Partners, LP, the lender parties thereto and Wells Fargo Bank, National Association, as administrative agent.

Incorporated herein by reference to Exhibit 10.1 to Form 8-K (#001-38629) filed on April 25, 2022.

10.08**

Equitrans Midstream Corporation Employee Stock Purchase Plan

Incorporated herein by reference to Exhibit 10.1 to Form 8-K (#001-38629) filed on April 27, 2022.

31.1

Rule 13(a)-14(a) Certification of Principal Executive Officer.

Filed herewith as Exhibit 31.1.

31.2

Rule 13(a)-14(a) Certification of Principal Financial Officer.

Filed herewith as Exhibit 31.2.

Section 1350 Certification of Principal Executive Officer and Principal Financial Officer.

Furnished herewith as Exhibit 32.

101

Inline Interactive Data File.

Filed herewith as Exhibit 101.

104

Cover Page Interactive Data File (formatted as Inline XBRL and contained in Exhibit 101).

Filed herewith as Exhibit 104.

* Management contract and compensatory arrangement in which any director or any named executive officer participates

** Management contract and compensatory arrangement in which any named executive officer participates

# Certain portions of the exhibits that are not material and is of the type Equitrans Midstream treats as confidential have been redacted pursuant to Item 601(b)(10)(iv) of Regulation S-K. Copies of the unredacted exhibits will be furnished to the SEC upon request.

Signature

Pursuant to the requirements of the Securities Exchange Act of 1934, the Registrant has duly caused this report to be signed on its behalf by the undersigned thereunto duly authorized.


			Equitrans Midstream Corporation
			(Registrant)


			By:			/s/ Kirk R. Oliver
						Kirk R. Oliver
						Senior Vice President and Chief Financial Officer

Date: May 3, 2022